Korean Journal of Construction Engineering and Management
/
v.8
no.3
/
pp.125-133
/
2007
If project time extension were required in the construction projects, either liquidated damages or extension costs should be applied according to causation of the schedule delays. However, in actual cases it is not applied so far according to the contract conditions. The reason why this situation happened Is that function of the present planning and scheduling is not working feasibly. The CPM schedule could not provide a proper solution for apportioning responsibility for the schedule delays. This situation could be considered as breach of contract and will cause potential disputes for schedule delay. Therefore, in this research process based contract administration model for construction delay claim is proposed to prevent schedule delay and solve the claims. The model is based on pro-active management for causation of delay to provide apportionment of responsibility and written evidences.
Jamal, Md Shah;Abdelaty, Ahmed;Shrestha, K. Joseph
International conference on construction engineering and project management
/
2022.06a
/
pp.616-623
/
2022
Some regions and states, such as Wyoming, have harsh weather conditions, forcing most transportation projects to be completed under tight schedules. However, construction projects are not only delayed by weather conditions, but also delayed by other factors such as contractor's competency, resource availability, coordination issues, and safety. Also, the construction method, geographical location of the projects, and inability to follow baseline schedules accurately due to the contractor's resource allocation are also reasons for the delay. This paper discusses the main reasons for the delay in the public transportation projects based on Daily Work Reports (DWRs) from five different transportation projects of the last three years in Wyoming. This paper focuses on the inconsistencies of the contractor's schedules to complete the project according to the baseline schedule. First, the authors collected DWRs and baseline schedules from the Wyoming Department of Transportation (WYDOT). Second, the DWR data are compared against the baseline schedules to determine the reasons for delaying their significance. Finally, the paper presents the recommendations to mitigate the effects of delays on public transportation projects as well as to improve the documentation process of DWR data.
International conference on construction engineering and project management
/
2005.10a
/
pp.897-901
/
2005
In the highway engineering, the performance, quantity and status of machines available for the project have direct impact on the project time. For instance, the status of machines, such as working or in trouble, have great influence on the activity execution. Therefore, while scheduling the project, the project manager always increases the spare machines or prolong the activity time to avoid delaying the project time when some of the machines are in trouble in construction site. However, how many are the spare machines and how long are the prolonged activity time, which are estimated subjectively by the manager. This subjective estimation has been criticized for systematically overestimating or underestimating quantity of the machines and the activity time. In the paper, we propose and prototype a model to simulate the status of the machines in construction site, and then to evaluate the schedule feasibility considering the performance, quantity and statues of the machines involved.
Kim, Seon-Gyoo;Lee, Yong-Hyun;Noh, Seong-Beom;Ko, Dae-Gyu
Korean Journal of Construction Engineering and Management
/
v.12
no.6
/
pp.54-64
/
2011
Almost 40 years have been passed since the CPM was introduced to the construction industry in Korea. However most of construction projects in Korea do not prepare the CPM schedule neither operate it after established manually, as well as still depend on the Bar-chart schedule only. One of these reasons is because the CPM schedule does not reflect the site works realistically, it makes so difficult to recognize the actual progress clearly in visual format, and it is impossible to integrate and manage the time and cost oriented work progresses effectively. This paper proposes new concept of progress management that is able to integrate and manage the time oriented schedule progress and earned value oriented cost progress while maintaining the merits of CPM although the CPM schedule summarized automatically within a schedule hierarchy by the BDM that is a new CPM technique. We expect that this concept could make the applications of CPM technique to the domestic construction industry popular and help the advancement of the construction management in Korea as well.
Journal of the Korea Institute of Building Construction
/
v.8
no.1
/
pp.49-56
/
2008
According to the recent trends which are the diversity of customer requests and the multi-function of buildings, A construction company's business has converted from the producer-oriented approach to the consumer-oriented approach. Therefore, each construction company is continuously trying to improve the quality level as a way of corresponding to customer needs in these changing situations. The quality is one of the main management targets which judge the success of a project along with the schedule, the cost and the safety. As construction companies execute the quality management which they aimed at, it should be completed within the optimum schedule and the limit of the budget. Accordingly, the importance of the construction site management to complete a project is continuously increasing. The construction site management is the systematic method to perform the project goals such as the quality improvement, the cost saving and the safety management, which organically operate one another, by procuring the manpower, the material and the machine in the right time. Specially, as the construction industry has based on the construction site, the establish of systematic construction site management, which can effectively correspond sudden changes of the construction business environment, is essential to maximize the construction productivity. On top of that, the necessity of the quality management method is increasing to accommodate customer needs more spontaneously in the construction site. These endeavors could guarantee their competitive power.
Korean Journal of Construction Engineering and Management
/
v.24
no.2
/
pp.13-23
/
2023
Unlike building construction projects, where the activity is repeatedly carried out in a limited area, civil engineering projects such as roads and railroads are carried out in a linear type in a horizontal working space over several tens of kilometers. Each activity is managed with a station number that has a unit of distance from the starting point to the end point. For this reason, since the work location information of the activity is a major management factor, the Gantt chart system that expresses only schedule information may have limitations. In this study, authors propose a method for constructing a linear schedule chart that can simultaneously express schedule information indicating the start and finish dates and location information indicating the start and end positions of each activity, and develop a system for generating a linear schedule chart. In the study, the coordinate axes of the linear schedule chart consisted of distance and date values on the X and Y axes, respectively, and each activity was expressed as a symbol that can infer the type of work to increase the visibility of the linear schedule chart compared to the simple bar chart method. The linear schedule chart generation system was reviewed for practical applicability by utilizing the actual schedule data of bridge structures in a railroad project.
International conference on construction engineering and project management
/
2015.10a
/
pp.147-149
/
2015
A nuclear power plant construction project normally involves a large construction work of which the total project cost is over 5 trillion Won, Such a large-scale construction project has the risks of schedule delay and quality degradation due to increase in project cost, because designs are changed due to design errors. The reasons for design changes during installation are 1) insufficient engineering capability of the owner, 2) information discontinuance due to the multiple package method, and 3) inefficient constructability review processes. Accordingly, this study proposes, through problem analysis, a method of developing a constructability review system that utilizes constructability review processes and a data-based technology (3D modeling) that are optimized for nuclear power plant construction projects. It also presents a method of establishing a system for reviewing constructability in which constructability review processes and a Database (3D model, Schedule, Design change Items) are linked each other.
Proceedings of the Korean Institute Of Construction Engineering and Management
/
2006.11a
/
pp.722-726
/
2006
Last Planner System (LPS) developed by Lean Construction Institute consists of four steps: Master Schedule, Phase Schedule, Lookahead Planning and Weekly Work Plan. This paper focuses on the process of measuring Percent of Plan Completed (PPC) at the Weekly Work Plan stage. PPC means the percentage of weekly assignments completed. According to the results of the researches that deal with PPC from many other countries, we can assure the benefits of using PPC. However, the concept of PPC is unfamiliar in Korea construction industry. This paper analyzes the cases in which PPC is applied in other countries and compares them with the production control system in Korean construction industry. The results of this research will provide the time management system for using PPC in Korea.
International conference on construction engineering and project management
/
2011.02a
/
pp.249-255
/
2011
Poor safety management in construction management may adversely affect cost, schedule and quality of a project. Heavy fines upon safety offence becomes a burden to the budget; losing working hours as a result of safety incident impacts on the schedule, and compromising quality is always an indirect consequence when workers perform duties in an unsafe site environment. Therefore, promotion of safety management becomes the top priority in any construction manager's agenda. Working safely will benefit construction project and lead to a "real" success. This paper is a case study, based upon "Geller's 10 principles for achieving a total safety culture", reviewing how a Hong Kong leading construction company fosters the safety culture and possesses a pleasant safety record over years. Its safety performance is not only well ahead the local industry, but also ranges top within the Asia Pacific region and comparable to those mature Western industries. The review concluded that safety culture is one of the major components in construction management and collaboration is the essence to realize this positive culture within an organization. Safety management is not merely a "top down" approach, but requires the positive "bottom up" actions from the other end. The successful story of this company can demonstrate the contribution of safety management in construction management.
International conference on construction engineering and project management
/
2013.01a
/
pp.352-358
/
2013
As amount of information in construction industry is growing, the role of information system in project management is becoming increasingly important. With the emerging IT application to the advancing construction industry, construction project management system with advanced technology has been progressed vigorously to improve construction productivity and management efficiency. Recently, a web-based Project Management Information System (PMIS) is developed to support decision-making process by efficiently managing project related information generated from various discipline. Many firms are in the process of developing the PMIS system or already have been applied the system to various projects. However, PMIS is still in its early stage of development to be applied at industrial plant construction projects that process management is significantly emphasized for the successful execution of the project. With the complexity of the industrial plant projects, the industry practitioners need to be able to visualize the construction schedule information to manage the project efficiently. This study suggests methodologies for improving PMIS specialized for industrial plant piping construction projects to estimate the baseline schedule and performance measurement more accurately by developing a framework for the piping construction projects. By using this developed system, the researchers expect that piping construction projects will be more efficiently managed on a real-time basis through measuring progress of piping at each and every state of progress milestone and provide management with opportunities to forecast the level of efforts required to execute the remaining work scope in a timely manner
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.