Journal of Construction Engineering and Project Management
/
v.2
no.3
/
pp.17-29
/
2012
Delays are one of the biggest problems facing by the construction industry and they have significant financial and social impact in construction projects. The paper presents a framework of Delay Analysis System (DAS) with the aim of analysing the impact of delay factors in Libyan construction projects. The system has designed by integrating the possible delay factors, critical activities of a project using@risk simulator. A case study of building project was demonstrated to identify the impact of delays and the sensitivity of delay factor. The case study result showed that the project might be delayed by 97 to 103 days in comparison to the planned duration. The developed DAS is a tool for analysing and identify the impacts of delay factors and assist to construction manager to take necessary measure in reducing the delay impact. The paper provides a methodology for analysing the possible delay impact in a construction project and informing to construction manager in advance of the possible delay factors.
Proceedings of the Korean Institute Of Construction Engineering and Management
/
2007.11a
/
pp.718-721
/
2007
Construction schedule plays a key role in project management due to its influence on the project success. Thus, it is important to identify factors affecting construction delay. The major objective of this study is to identify and evaluate factors affecting construction delay in apartment projects in Vietnam. The findings confirmed that financial difficulties of owners and contractors, contractors without adequate experience, non-available materials on time, slow site clearance, inappropriate construction methods, defective works and reworks, and lack of capable owners/project managers are the major causes of delay in apartment projects.
Korean Journal of Construction Engineering and Management
/
v.7
no.5
/
pp.177-190
/
2006
Construction projects are facing delay problems. Delays in construction have been immense effect on performance or satisfactory delivery of the project. Delays have been causing project cost overrun as well as it is a source of dispute hence damaging the relationship between the project participants. The purpose of this study was to explore the causes of delay risk through a field survey study. Data were collected from construction professionals working in owner, consultant and contractor organizations. All together 208 questionnaire instruments were used and analyzed by employing statistical tools (SPSS computer program). 19 delay factors were identified by this study, out of which following factors were critical: Frequent interruptions from public (local people, pressure group etc.), changed site condition, failure to provide required construction site, unrealistic project time estimation and design errors.
The block-unit housing renewal project was presented as an alternative method to overcome the side effects of large-scale renewal projects while improving poor residential conditions. However, projects implementation is prolonged and even the pace of projects, which was considered an various incentives, is being delayed for the most part. In this study, delay factors are drawn by eight; conflict among association members, contract delay of joint implementation, participation paucity of constructor, inadequate project guidelines, alteration of project plan, lack of renewal project professionals, stricter loan restriction of HUG, lack of capacity of project operator. We categorized those eight factors to three aspects such as implementation, participants and proposition and suggested improvement alternatives according to three aspects.
Large-scaled hospital information system projects are often delayed than originally planned. Regarding project management, it is necessary to examine main factors triggering the schedule delay and to analyze the causality of such delay. This study tries to find the delay factors and causal relationship between them based on the case of the hospital information system development project by using the grounded theory method. It turned out that 'unrealistic scheduling' affects overall schedule delays like domino phenomenon, and 'poor analysis of existing systems' leads to poor quality of work analysis while 'poor subsystem integrated interface' triggers poor design quality. This study found out the factors affecting the delay of a project, analyzing cause-and-effect relationships between them in the academic side. From the practical view, it shows a solution to minimize delays in the project schedule for each of SI companies, hospitals and project managers.
International conference on construction engineering and project management
/
2015.10a
/
pp.527-531
/
2015
With the mounting concerns over environmental issues, green construction is gaining a place in the global construction industry. However, rare research has been conducted to analyze green construction projects, especially in the aspect of project schedule performance. As a result, this study aims to investigate the degree of project delay in green building construction, analyze the factors affecting schedule delay of green building projects, and finally provide recommendations to improve schedule performance of green building project. To achieve the objectives, a comprehensive literature review was carried out, followed by a survey conducted with 30 companies that provided data from 220 traditional and 96 green building projects. The analysis of the responses identified that 15.9% of the traditional building projects were delayed while 32.3% of the green building projects were completed behind schedule. Furthermore, the amount of the delays in green building projects was an average of 4.8% of their planned schedule. The top 5 critical factors that can cause delay in green building projects were identified as: (1) speed of decision-making by clients; (2) speed of decision-making involving all project teams; (3) communication/coordination between key parties; (4) level of experience of consultants; and (5) difficulties in contractors' project financing. Lastly, a list of recommendations was introduced, aiming to reduce schedule delay in green building construction projects based on the observations. This study will serve as s a base for further research on the enhancement of green building project schedule performance.
Journal of the Korea Institute of Building Construction
/
v.11
no.1
/
pp.9-17
/
2011
Project delay is one of the most crucial impact factors in the construction process from a schedule and cost management perspective. This study focused on analyzing the causes of concrete frame work delay in the apartment construction project. According to the analysis of project cost composition, the direct cost of concrete works was highest in most samples. Actual delays of concrete works were analyzed for the six different construction components. Causes of delay were grouped into two categories; preconstruction and construction phases and these two groups were further divided into sub-groups. Analysis results revealed that the most significant delay was occurred in the 1st. floor concrete skeleton work. For each delay factor, implications of delay as well as suggestion(s) for reducing the possibility of schedule delay are provided.
International conference on construction engineering and project management
/
2011.02a
/
pp.614-620
/
2011
Delays in completing construction projects have significant financial and social impact to all parties involved in the construction process and in particular in developing countries. This is very evident in most construction projects in Libya and in both public and private sectors. The research study was initiated by Libyan Government and the main aim of the project is to develop a new strategy in reducing the impact of delay factors. In order to achieve this, a number of objectives have been set-to conduct a comprehensive literature survey, to conduct a comparative study of the delay factors in project completion in both Libya and UK using semi structured questionnaire and finally, to identify and analyse the causes of delay and ranked them using frequency of occurrence and severity. The critical causes of delay for construction projects were quite different between Libya and UK. For the former, the most critical causes of delay in Libyan construction industry were low skills of manpower, changes in the scope of the project, slowness in giving instruction and poor qualification of consultant, while for the latter they were financial problems, bad weather conditions on the job site and change in the scope of project. Statistical experiments including Paired Samples T-Test, was run to test the significance of the survey data in both countries Libya and UK. The statistical results confirmed the collected data from the survey were significant.
Journal of Construction Engineering and Project Management
/
v.4
no.3
/
pp.33-46
/
2014
Delay is the most common problem in the construction industry. It has many negative effects on project's success in terms of time, cost, quality, and safety. From the literature review, a total of thirty-five factors of delay were selected. These factors were divided into seven groups related to materials, manpower, owner, consultant, contractor, construction, and external problems. This study was carried out to identify the main causes of delay for a construction project through their importance level. The importance level was determined based on the frequency of occurrence and severity of impact. The structured questionnaire has distributed to the respondents who have much experience in construction management in Bangladesh. The results of analysis indicated that top five factors of construction delay according to their level of importance are: (1) price of construction materials increased very rapidly, (2) political situation (revolution/ public strikes), (3) shortages of skilled workers, (4) poor site management and supervision by contractor, (5) incompetent/ immature subcontractors. These findings of this study are expected to be significant contributions to Bangladesh construction industry in controlling current performance of project on time overrun.
Luu, Van Truong;Kim, Soo-Yong;Pham, Nguyen-The-Thanh;Nguyen, Thanh-Long;Nguyen, Tuan-Kiet
International conference on construction engineering and project management
/
2015.10a
/
pp.104-108
/
2015
Delay on State-Funded Construction Projects (SFCPs) in Dong Thap - a province in Mekong Delta of Vietnam, as many provinces of Vietnam, have caused budget overrun through many recent years. The budget-overrun situations, in turn, have deepened the delay. Identifying critical factors affecting delay SFCPs plays a key role to mitigate negative impact of delay. 134/160 questionnaires were collected from personals working for project owners, consultants, supervisors and contractors in Dong Thap Province. Convenient sampling method was used. EFA was resulted in critical 04 factors with 20 variables caused delay in SFCPs, including: "Project technic, contractor's financial capacity and adjustment role of the government", "Regulation and Policy", "Mutual benefit support and concern between the government and residents", and "Disadvantage of construction site and weather season". Reliable measures to reduce delay on SFCPs are discussed to establish legal corridors to strictly controlling the process, consider mutual benefit between the government and its residents, and evaluating construction conditions. Those measures are considered could be applied in not only Dong Thap province, but most provinces of Vietnam as well.
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.