Korean Journal of Construction Engineering and Management
/
v.9
no.5
/
pp.214-226
/
2008
Construction delay caused considerable losses to project parties. Avoiding construction delays is important to save costs for project stakeholders. The main objective of this paper is to identify major causes of construction delays of apartment construction projects in Vietnam. Sixteen causes of delay were identified through a questionnaire survey of 166 professionals. Factor analysis was employed to categorize these causes. The results of the survey revealed the main causes of delay of apartment projects in Vietnam are: (1) owner's and contractor'S financial difficulties; (2) lack of experienced contractors; (3) late delivery of materials; (4) late construction site handover; (5) owner's late payments for completed works; (6) low bid prices; (7) inappropriate construction method; and (8) defective works and unnecessary reworks. Factor analysis uncovered that causes of delay can be grouped under five categories labeled the five INs: incompetence, ineffectiveness, inadequateness, inapplicableness and inconceivableness. Comparative analysis between the Vietnam construction industry (VCI) and the Korea construction industry (KCI) has been performed to infer valuable lessons for researchers and practitioners in the VCI and the KCI. Comparative analysis indicated that main causes of delay in the VCI somewhat differ from main causes of delay in the KCI. However, "contractor'S financial difficulties", "late construction site handover", "unnecessary rework", "incapable designers", "site clearance difficulties" are common causes of delay in the VCI as well as the KCI. The findings of this research can be used as a guideline to overcome problems in the VCI as well as in other construction industries. Since Korea has emerged as the first largest foreign investor in Vietnam, the results of this study may be useful not only to practitioners and researchers in Vietnam but also to participants in Korea.
Proceedings of the Korean Institute Of Construction Engineering and Management
/
2007.11a
/
pp.446-449
/
2007
For the restoration of construction industry, the government have offered the policy since the end of 1990. It has offered to develop the world-class technology and establish the effective production structure. In the government policy, the delivery and contracting method has improved so that construction industry could be recognized. Foreign countries have conducted the R&D and application of Innovative Contracting for improvement of facilities, reduction of LCC and innovation of contractor. Among the Innovative Contracting, 'Performance Warranty Contracting' is defined that A guarantee of the integrity of a product and of the makers responsibility for the replacement or repair of deficiencies. Performance Warranty Contracting is used for technology developments of contractor, improvement of quality, reduction of LCC, prevention of early deficiencies and reduction of owner's inspection works. This paper analyzes concept and effects of Performance Warranty Contracting and presents considerations according to the introduction.
VU, Thong Quoc;PHAM, Cuong Phu;NGUYEN, Thu Anh;NGUYEN, Phong Thanh;PHAN, Phuong Thanh;NGUYEN, Quyen Le Hoang Thuy To
The Journal of Asian Finance, Economics and Business
/
v.7
no.9
/
pp.389-400
/
2020
A construction project is a designed product made up of labors, materials, and installations in the project positioned on the ground and may include the underground and ground section, and the section in water or on the water surface. It is a civil, industrial, transport, agricultural and rural development, infrastructure, or some other. A key phase in the life cycle of these construction projects is the implementation when building products are made directly with workers, equipment, materials, and managers. If there is a lack of management experience, information, and problem-solving solutions to tackle the risks faced by contractors, especially foreign ones, will fail in controlling the project's cost. This study was conducted with investigations, discussions, and evaluation of the factors that lead to cost overruns in the construction projects of international contractors in Vietnam. The principal component analysis (PCA) showed that those factors that influence cost overruns these construction projects fall into five general groups, including factors related to (i) the owners, (ii) the foreign contractors, (iii) the subcontractors and suppliers, (iv) state management, and (v) the project itself. Besides, the study proposes solutions to limit cost overruns in construction projects and improve the profitability of international contractors in Vietnam.
The Assembly plenary session on December 3, 2017 passed a Product Liability Amendment bill that introduced clauses concerning consumer burden of proof and punitive damage reimbursement. More specifically, these newly approved provisions will reduce the burden of proof placed on consumers and levy triple punitive damage on suppliers. Significant increases in the number of product-liability lawsuit and the number of related insurance contracts are expected. Since military aircraft are designed for operational purpose(seeking greater combat effectiveness over greater safety) and used in high-risk environment, it is practically impossible to obtain an affordable product-liability insurance, Without having any backup plan, military aircraft manufacturers directly face all sort of liability risks under Product Liability Act, Warrant Liability Act and Non-Performance of Contract Act. The U.S. experienced similar problems when they first implemented their product-liability law in 1970s. There had been a big dispute among legal practitioner, insurance professionals and scholars concerning military aircraft manufacturer's liability. In order to settle the issue, the U.S. Supreme Court has established a new precedent of Government Contractor Defense(GCD). The U.S. government also included an indemnity clause for military aircraft manufacturers in their FMS Contract with the Korean government. Likewise, Korean military aircraft manufacturers should 1) clearly understand their current position that they cannot afford expensive product-liability insurance and the cost is not accounted in the military procurement calculation, 2) estimate potential liability risks with the ongoing overseas export expansion in mind, 3) set up appropriate risk management measures through regulatory reform and policy development.
Journal of the Korea institute for structural maintenance and inspection
/
v.21
no.3
/
pp.9-18
/
2017
Construction Management at Risk (CMAR) is a project delivery method that enables CM companies to deliver projects at a Guaranteed Maximum Price (GMP). General contractors can apply CMAR from the initial design phase right through the construction phase to reduce risks and improve project performance. One of the major advantages CMAR offers is that it permits a general contractor to provide a comprehensive suite of preconstruction services, including estimating, a constructability review, value engineering, drawings and a specification review, green building, and Building Information Modeling(BIM), among others. However, general contractors in South Korea currently provide only limited preconstruction services using CMAR because few CMAR projects have yet been implemented in Korea and their experience using the method is therefore limited. This benchmark study of how foreign general contractors utilize CMAR in their projects, particularly during the preconstruction process, its purpose, and the roles and responsibilities of each of the different participants in successful implementations thus provides invaluable information and will serve as a useful guide for Korean contractors seeking to incorporate CMAR preconstruction services in their projects and thus improve the competitiveness of their construction businesses.
Korean Journal of Construction Engineering and Management
/
v.22
no.4
/
pp.20-28
/
2021
The Domestic Construction Industry is in the process of changing from a one-sided production method centered on the contractor to a production method in which the order and the contractor can collaborate. Depending on the delivery method, the bid/success method, the contract method, and the degree of business involvement of the order may also vary. In this thesis, in order to introduce 'Construction Management at Risk' suitable for the domestic environment, domestic and foreign institutional analysis, bid process analysis, contract fulfillment and management analysis, post management analysis, and related laws and regulations for legalization In order to suggest a plan for the efficient operation of the system, a system and case analysis of domestic and international construction responsibility type construction project management was conducted. 'Construction Responsible Construction Project Management' defined in the Framework Act on the Construction Industry is divided into the main contract transfer contract, which is a service contract performing pre-con work, and the main contract, which is construction project management and construction contract. Therefore 'Construction Management at Risk' should be regarded as one of the ordering methods rather than a successful bid system, as in the case of overseas, and legalization as a bidding system equivalent to design/construction batch bid and technology proposal is necessary for introduction. In order to introduce 'Construction Management at Risk' suitable for the domestic environment, domestic and foreign institutional analysis, bidding process analysis, contract fulfillment and management analysis, and follow-up management analysis are conducted. A method for efficient operation was suggested so that it can be applied in the domestic market while maintaining the original merits of this system.
In order to carry out construction work, it is urgent to introduce a proper wage system so that the cost burden of projects that have been won due to bleeding competition among original government buildings based on low-priced bids can be transferred to subcontractors. Purpose: Construction with illegal multi-level industrial structure needs to improve the wage reduction environment leading to order (100%) → original contractor (80%) → subcontractor (65%) → load contractor (65%) and aims to ensure wages for end workers. Method: Investigate the current status of labor cost appropriate payment plan in the construction industry, and investigate the case of the appropriate wage system (P.W) in the United States. In addition, the effect and direction of the appropriate wage system are presented. Result: Individual minimum wage security was also mentioned in the Constitution, and many researchers suggested that only the introduction of an appropriate wage system could solve the problem of reducing worker labor and ensure quality and safety. Conclusion: The proper wage system in the construction industry will block illegal multi-level and illegal foreign work, improve the labor environment in the construction market, create an influx of young workers, and have a significant impact on the construction industry's competitive structure, safety, and quality.
Kim, Sang-Chul;Park, Chan-Jeong;Lee, Sang-Youb;Son, Jae-Ho
Korean Journal of Construction Engineering and Management
/
v.8
no.5
/
pp.109-118
/
2007
It is related to launch the CM market and to increase the profit and entire ability in company that is enforcing the ability of construction management in large-scaled construction company. According to the CM market in U.S, CM market is increased with competing to the companies, that is E&C, general contractor, design firm, specialized CM firm. Also domestic market is similar to US market. In this situation, large-scaled construction companies are filled with construction management ability for competing with foreign companies and domestic CM firms. This paper suggests how to enforce the construction management ability through education, and shows the detailed education strategy considered the fields, divisions and positions.
Korean Journal of Construction Engineering and Management
/
v.15
no.2
/
pp.95-103
/
2014
From $1960^{th}$ Korean construction industry has been rapidly grown due to Meddle-East construction market growth. To earn foreign currency and to raise overall Korean industry government has encouraged construction frontiers. As construction industry could grow up for its labour based originity but the time passes by and overseas construction market requests engineering know-how and technology for productivity to earn more profit. Over last 20 years overseas construction market share has been dramatically raised but its profit share is gradually declining. This study analyzed data sets of over 180 overseas construction projects for last 30 years of domestic contractor by using multiple-regression analysis and derived an output how input variables of characters explaining the construction project effects its profit.
Many Korean construction companies have been performing a variety of overseas construction projects since the 1970s. It is unfortunate that in many cases they have had to suffer big losses caused by errors and defects in the design and construction of the projects. In the author's opinion, however, there were losses that could have been avoided if they had understood better the feature and content of the particular construction contract. Few lawyers and scholars in Korea have been interested in the research and study of international construction contracts. This is mainly because they do not have access to practical sources outside of Korea for them to research and study since the contracts undertaken have been dealt with by law firms in other jurisdictions to which the disputes apply. This article is aiming primarily at the introduction of the issues which the practitioners are likely to confront in the process of reviewing and performing the international construction contract. In some cases solutions are sought about these issues based upon the FIDIC standard terms and conditions, the actual experience of practice, and UNIDROIT Principles, etc. It is reasonable to say that all the issues related to the international construction contract cannot be covered in a short article like this. The author wishes this article could induce subsequent studies on international construction contracts for further research. It has to be noted that from time to time Korean construction practices have been compared to the international ones for better understanding. This article mostly includes cases where the Korean construction companies go overseas for their projects, while there are some cases where foreign developers and financial investors participated in domestic projects in which international construction contracts forms were adopted. A few precedent domestic writings about international construction contracts seems to lack emphasis on the points that there are several standard construction contract forms and that they are different. The differences are mainly in accordance with who bears the design responsibility, how the owner has to make progress payments to the contractor and who the funding source for the project is. This article tries to make it clear that there are significant differences between the standard contract forms, e.g. a simple construction form, a design-build form and an EPC/turnkey form of contract. Again, the author hopes that this article can arouse the interest in the international construction contracts from both academic and practical fields, so that many subsequent advanced articles can help our construction industry become much more competitive in the world through awareness of the methods of procurement and administration of the contracts.
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.