International conference on construction engineering and project management
/
2020.12a
/
pp.207-215
/
2020
The purpose of this study is to investigate the current status of claim management process of general contractors in South Korea. As the claim management becomes more important nowadays, maintaining the process for claim management systematically and consistently becomes more important as well. To improve the claim management process, it is necessary to diagnose the current status of claim management process so companies establish their targets for improvement. This study develops a survey to identify the current status of claim management process that major general contractors in South Korea have. Questions in the survey are classified into four categories including entitlement check, potential claim event check, time bar check, and tasks for substantiation. By conducting a series of statistical analyses with 94 survey data collected from employees working in the general contractor companies in South Korea, this study examines and analyzes their claim management process in terms of the several categories. It is expected that the results contribute to diagnosing how practitioners maintain their claim management, which will help them establish the direction of management enhancement.
International conference on construction engineering and project management
/
2007.03a
/
pp.160-168
/
2007
Conflicts of interest and independent agenda of the parties brought together for implementation of a construction project often leads to dispute in Contract and claim situations. Construction Industry is notorious for claim that is managed on its arising and there lacks an endeavor to minimize the breeding grounds through efficient planning and alignment to purpose, of all contract-documents. There failure of a concerted effort entails wastage of resources, delayed completion of facilities and stained relationships of parties when collide in mistrust in contract to win over the other. There needs a focus on the claim breeding issue and establish an effective mechanism to deal with disputes in urgency. Claim occurs mostly during the construction phase. But the seeds of claim and nutrients essential for development are contained in the contract documentation and the information supplied or not in pre-contract phase. Opportunity to prevent nutrients for seed of Claim comes to an end once tender-documents are finalized, the contract is awarded and established or not a mechanism for dealing with claim situation. The processes presented here would help in minimizing the breeding grounds and emergence of disputes during progression of works and dealing with eventualities in forceful manners for finding a resolution most effectively in relevant time.
Proceedings of the Korean Institute Of Construction Engineering and Management
/
2007.11a
/
pp.463-468
/
2007
The disputes in construction projects are very important issue for stakeholders. However, many of presented claims have not received the compensation money required, and frequently turned down. The most cause is that the claims are not managed systemically on construction. Therefore, it is important to identify which management works are conducted on construction and how significantly do they relevant to construction claim. This research derives key claim management factors through analyzing causes for claim success and failure, and then presents management works relevant to them. This research also proposes the method for effective claim management and its expected effect through expert interview.
Korean Journal of Construction Engineering and Management
/
v.12
no.1
/
pp.13-22
/
2011
Many studies on cause and prevention of claim have been carried out but they were mostly intended to come up with the improvement measures, improvement system or the measures to deal with the claim, which consequently lacked the substantial ways to identify the details of claim for prevention purpose. That is, there's in fact no tool, in preparation for potential claims, to identify and review the major potential causes at design stage to mitigate the claim and thus, it's necessary to develop the tool such as checklist needed to prepare the claim-supporting documents, check the relevant laws as well as to identify the cause of claim. Hence the study, given the fact that cause of claim is mostly generated at the design stage though the claim itself tends to occur at the construction stage, was aimed at developing the checklist based on contract document such as design documents at design stage for public construction projects in a bid to prevent the potential claim occurred at the design stage.
Objectives : This study examined the health policy researchers' needs and their accessibility towards health insurance claim datasets according to their academic capacity. Methods : An online questionnaire to capture relevant proxy variables for academic needs, accessibility, and research capacity was constructed based on previous studies. The survey was delivered to active health policy researchers through three major scholarly associations in South Korea. Seven-hundred and one scholars responded while the survey as open for 12 days (starting on December 20th, 2010). Descriptive statistics and logistic regression analysis were carried out. Results : Regardless of the definition for operational needs, the prevalent needs of survey respondents were not met with the current provision of claim data. Greater research capacity was shown to be correlated with increased demand for claim data along with a positive correlation between attempts to obtain claim datasets and research capacity. A greater research capacity, however, was not necessarily correlated with better accessibility to the claim data. Conclusions : The substantial unmet need for claim data among the healthcare policy research community calls for establishing proactive institutions which could systematically prepare and make available public datasets and provide call-in services to facilitate proper handling of data.
In many non-life insurance applications past data are given in a form known as the run-off triangle. Smoothing such data using parametric crisp regression models has long served as the basis of estimating future claim amounts and the reserves set aside to protect the insurer from future losses. In this article a fuzzy counterpart of the Hoerl curve, a well-known claim reserving regression model, is proposed to analyze the past claim data and to determine the reserves. The fuzzy Hoerl curve is more flexible and general than the one considered in the previous fuzzy literature in that it includes a categorical variable with multiple explanatory variables, which requires the development of the fuzzy analysis of covariance, or fuzzy ANCOVA. Using an actual insurance run-off claim data we show that the suggested fuzzy Hoerl curve based on the fuzzy ANCOVA gives reasonable claim reserves without stringent assumptions needed for the traditional regression approach in claim reserving.
KINITI implemented a claim system with EDI. This paper presents the way in which electronic data interchange(EDI) can be used to assist in the management of claim information and describes the definition, structures, benefits, problems of EDI and future enhancement.
Purpose - This study is designed to provide new insights on trade claim management by typifying trade claims from a relational perspective, which defines trade as an organic combination that exchanges relationships based on a mutual goal instead of conflicts between obligations and rights of the contracting parties. Design/methodology - This is a phenomenological study that aims to typify trade claims based on a relational perspective and extract implications for trade claim management. The research procedures of this study are as follows. First, international commercial dispute cases applying the CISG are collected. Second, the cases collected are quantified through content analysis. The variables for quantification are developed based on a relationship perspective. Third, cluster analysis is conducted on coded data to typify cases. And finally, this study compares the characteristics of each type using analysis of variance and suggests implications for the strategic management of trade claims from a relational perspective. Findings - Results show that trade claims are divided into four clusters, depending on whether flexibility is accepted or not and which party violates mutuality. There is also a difference between the claimant and the cause of the claim, according to the cluster. Based on the results, this study suggests that the buyer and the seller should employ different strategies depending on the type of trade claim and presents proposals for strategic claim management. Originality/value - Firstly, this study extends the theoretical discussion on trade claims by applying relational contract theory. Prior studies on trade claims have been primarily based on traditional contract theory. The second is to analyze trade claims quantitatively. Prior case studies on trade claims have mainly relied on qualitative research. Finally, the study contributes to international commercial practice by typifying trade claims and presenting options for strategic management.
Korean Journal of Construction Engineering and Management
/
v.18
no.3
/
pp.22-32
/
2017
Judging from the past cases, the contractor has frequently suffered losses caused by disapproved requests or reduced payments since it has not known the conditions of the contract or it has filed a claim to the owner without any proper claim system. Therefore, the existing claim process needs to be reformed. In order to reform the claim process, the contractor should consolidate the organizational structure, grant accurate duty assignments to the claims manager, implement regular staff training on how to deal with claims. In addition to this reformation, the contractor needs to improve the management of construction period and process control, and manage related documents thoroughly. Regular meetings are also necessary in claims. This study attempts to prove the effectiveness of the reformed process applied to Project "A", where the owner was responsible for the delayed supply of materials, inaccurate oral instructions, insufficient information on the work, and frequent changes of design. The project was completed in 96 months, which was extended by 34 months from the initial construction period of 62 months. The reformed claim process is expected to be of great help not only to largescale construction works but also to smallscale ones.
Korean Journal of Construction Engineering and Management
/
v.17
no.5
/
pp.35-44
/
2016
Various risk factors are known to be the nature of construction project execution process. These factors lead to potential claims, dispute mediation, arbitration, and litigation which can result in huge loss of money and time. Therefore, it is necessary for construction companies in Korea to improve overall project management capability through the evaluation before entering into the overseas construction market. Also, after examination of the claim and dispute caused by construction project risks, a substantial degree of influence and active preparation for the claim and dispute management should be confirmed via the effect analysis of the each factors. Main claim causes were derived through claim and dispute cases involved with domestic construction projects. As a prediction result of the main claim, 16.1% of the construction change claim, 5.7% of the bad faith claim and 2.7% for the construction delay claim were found to be the portion of the total construction cost. As a result of this analysis, risk management methodology was suggested to improve a project management capability for domestic construction companies through analysis result of the main factors of construction claims.
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.