KSCE Journal of Civil and Environmental Engineering Research
/
v.26
no.5D
/
pp.839-848
/
2006
Korea has become the 5th country to own and operate the high speed railroad in 2004. However, there were many difficulties until Koreans enjoy the first bullet train service with the average hourly speed of 300km. The high speed railroad requires elevated quality standards differently from the traditional railways. In addition to the technical difficulties, the construction project itself was an unpleasant case with huge delays and cost overruns mainly due to the lack of experiences, deficiency of owner$^{\circ}{\O}$s role, and increase of public resistances triggered by environmental concerns. This paper analyzes the reasons for delays on this mega-project. With respect to the characteristics of the whole project level, it is very complicated/linear project, whose total length is around 412 km with the composition of various sections in the route of the railway which have basically different conditions. For that reason, the analysis is performed in both macro and micro level. First, macroscopic analysis is performed to find critical subdivisions in the railway route that induces the significant delay in the opening due date. Then, microscopic analysis is followed to quantify the causes and effects of delays focused on these critical subdivisions in more detailed way. Finally, this paper provides lessons learned from this project to avoid the decisive delays in performing the similar large-scaled projects.
Journal of the Korea Institute of Building Construction
/
v.11
no.1
/
pp.9-17
/
2011
Project delay is one of the most crucial impact factors in the construction process from a schedule and cost management perspective. This study focused on analyzing the causes of concrete frame work delay in the apartment construction project. According to the analysis of project cost composition, the direct cost of concrete works was highest in most samples. Actual delays of concrete works were analyzed for the six different construction components. Causes of delay were grouped into two categories; preconstruction and construction phases and these two groups were further divided into sub-groups. Analysis results revealed that the most significant delay was occurred in the 1st. floor concrete skeleton work. For each delay factor, implications of delay as well as suggestion(s) for reducing the possibility of schedule delay are provided.
Proceedings of the Korean Radioactive Waste Society Conference
/
2010.05a
/
pp.21-22
/
2010
정부는 방폐장 부지선정에 19년을 소요하였다. 이 후 방폐장 특별법에 따라 주민투표를 실시하였으며 그 결과 2005년 12월에 경주로 결정되었다. 2008년 8월 실질적인 공사가 시작 되었으나 2009년 6월 방폐물공단에서는 30개월의 추가적인 공기가 필요하다며 준공지연을 발표하였다. 이 준공지연발표 직후 방폐장 안전성 논란이 불거졌다. 감시기구에서는 안전성 논란의 출발이 준공지연으로 야기되었음을 인식하고 준공지연 원인분석을 하였다. 그 결과 감시기구에서 확인한 준공지연의 원인은 당초 실현하기 매우 어려운 공기를 설정한 것이며 또 이를 실현 가능한 공기로 수정(준공지연)하는 과정에서 과거의 오류를 인정하지 않고 공사의 어려움을 검토한 내부문서가 유출되어 시민들을 혼란스럽게 한 것이 주된 이유임을 확인하였다.
Proceedings of the Korean Institute Of Construction Engineering and Management
/
2007.11a
/
pp.637-642
/
2007
The sum of each work duration are entire period in construction project. Each work occurs to be late, the total period of construction project will delays. Therefore, the total period of construction project will not be delayed if probability of working progress makes higher. Finding each work's constraints performs constraints analysis in process of construction for checking probability of working progress. Grasp work's constraints through the constraints analysis and removes. This research will show preventing delay of consruction project, through constraints analysis process.
Proceedings of the Korean Society of Tribologists and Lubrication Engineers Conference
/
1996.04b
/
pp.99-105
/
1996
공기 베어링은 마찰과 열 발생이 적고 회전 정밀도가 우수하여 고속 회전하는 축을 지지하는 용도로 많이 사용되고 있다. 그러나 공기 베어링도 유체 베어링이라면 어느것이나 갖는 Whirl 불안정성이라는 치명적인 결점을 갖는데 현재 이것의 발생 시점이 공기 베어링을 사용하는 시스켐에 있어서 고속화의 한계로 되어있다. 본 논문에서는 불안정성의 원인이 되는 동압 발생을 억제할 수 있는 방법으로 베어링의 위치가 축의 위치에 대해 일정한 각도 지연을 갖도록 제어되는 것을 제안하고 여러 각도지연 크기와 제어게인에 따른 안정특성을 이론 해석을 통해 조사하였다.
Korean Journal of Construction Engineering and Management
/
v.12
no.6
/
pp.31-41
/
2011
Since the cases of time extension have continuously transpired in the public construction project, the potential of economical loss and claims is increasing because the concerned parties such as an owner or a contractor have not properly performed their own responsibility for time extension. One of the main reasons is that the present planning and scheduling do not support the method to apportion the proper responsibility to the right party. This problem has repeatedly led to time extension and made it difficult for the concerned parties to perform the responsibility for time extension. In order to overcome this problem, a framework of delay administration is required as the method to apportion the proper responsibility to the right party. To solve this problem, this paper aimed to develop the conceptual model and prototype system as the practical method to administrate delay causation. Furthermore, the verification result for the reliability and applicability throughout the case studies on real construction projects shows that the conceptual model and prototype system developed would help efficiently to administrate the delay causation.
Journal of the Korea Institute of Building Construction
/
v.20
no.6
/
pp.527-535
/
2020
This study analyzed main causes of claims in EPC/Turnkey projects. For this purpose, this study referred to the FIDIC silver book, which lists the international standard contract conditions for EPC/Turnkey projects. The most frequent cause of claim was delay. A process was then proposed to determine whether the owner or contractor was the responsible party when the delay claim occurred. The proposed process was for damages for delay which is the conditions of contract for indemnities against delay claim. The process was based on conditions of the contract of two previous EPC/Turnkey projects that were constructed in 2010, the FIDIC silver book, as well as the obligations of owner and contactors. The proposed process is applicable depending on the conditions of the contract and the owner's meaning. Furthermore, by identifying the responsible party, this study will contribute in identifying the possible claim types before concluding a contract and writing the specific contract.
Korean Journal of Construction Engineering and Management
/
v.10
no.1
/
pp.36-44
/
2009
The sum of each work duration are entire period in construction project. Each work occurs to be late, the total period of construction project will delays. Therefore, the total period of construction project will not be delayed if probability of work progress makes higher. Finding each work constraints performs constraints analysis in process of construction for checking probability of work progress. Grasp work constraints through the constraints analysis and removes. This research will show preventing delay of construction project, through work condition analysis process.
KSCE Journal of Civil and Environmental Engineering Research
/
v.29
no.6D
/
pp.737-743
/
2009
Shield TBM, since it was employed for Suyoungman Bay riverbed tunnel of Busan Subway in 2000,has been increasingly adopted in Korea, and in line with growing popularity, the study on Shield TBM has been expanded. However the studies mostly focus on ground condition in a bid to estimate the advancement rate and develop the model for calculating the excavation efficiency, whereas the efforts to analyze the cause of delay and to develop the improvement measures have been neglected. Thus the studies were mostly intended to analyze the schedule slippage focusing on ground conditions, while the study on schedule behind due to equipment itself and related facilities have yet to be attempted in earnest. This study hence was aimed at evaluating the troubles and schedule slippage caused by mechanical elements such as shield TBM equipment and tools and ground conditions, making use of FMEA approach so as to analyze the risk of schedule delay by such elements, thereby proposing the preventive measures to deal with high-risk factors. So, this study suggest the solution to highly ranked trouble factor for the purpose of enhance the efficiency on Shield TBM.
Proceedings of the Korean Institute Of Construction Engineering and Management
/
autumn
/
pp.287-291
/
2002
A construction claim is generally caused by several causes, and in the case of developed countries, the most fundamental problem in most claims is a delay claim. Also, it is predicted that the trouble will increase by this one in a domestic case as well. Even though the construction claims occurred by the delay claim are the most frequent ill construction project, it is very difficult to analyze due to the complexity of occurring forms. Therefore, the rational judgement and the solving method need to be concerned through the accurate understanding the clauses accepted in a international contract execution and a domestic contrail when the claim occurred. The purpose of this study is to present problems and improving methods by comparing FIDIC with a domestic accounting regulation in order to expand a general condition into the international contract condition.
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.