Journal of Construction Engineering and Project Management
/
v.7
no.3
/
pp.1-14
/
2017
Delay claim should actually be supported by a set of proper information so that the contractors could prove their validity. The so-called information should be able to clarify the relationship between delay events and how they impact on the whole project. Therefore, exploiting an integrated system by people who are involved in construction business would certainly prove helpful. In the present study, delay analysis methods have been investigated along with selecting a relatively comprehensive method which has been modified, and eventually, a novel model and its required modules have been proposed for evaluating delay claims. The suggested integrated model is formed to identify delayed events, to classify delays, to measure the impacts of delays on the project scheduling, and finally to estimate the damages which were caused by those so-called delays. A decision support system (DSS) model which is related to the integrated system is actually extracted from Iran's general contract conditions, that is, 4311 magazine (equivalent to red FIDIC book). It is then programmed and coded by C# program. This DSS model can be used as an input of Easy Plan program. In addition, at the end of this research, the coded DSS has been used along with the so-called program so that a modified and developed model could be generated.
International conference on construction engineering and project management
/
2011.02a
/
pp.614-620
/
2011
Delays in completing construction projects have significant financial and social impact to all parties involved in the construction process and in particular in developing countries. This is very evident in most construction projects in Libya and in both public and private sectors. The research study was initiated by Libyan Government and the main aim of the project is to develop a new strategy in reducing the impact of delay factors. In order to achieve this, a number of objectives have been set-to conduct a comprehensive literature survey, to conduct a comparative study of the delay factors in project completion in both Libya and UK using semi structured questionnaire and finally, to identify and analyse the causes of delay and ranked them using frequency of occurrence and severity. The critical causes of delay for construction projects were quite different between Libya and UK. For the former, the most critical causes of delay in Libyan construction industry were low skills of manpower, changes in the scope of the project, slowness in giving instruction and poor qualification of consultant, while for the latter they were financial problems, bad weather conditions on the job site and change in the scope of project. Statistical experiments including Paired Samples T-Test, was run to test the significance of the survey data in both countries Libya and UK. The statistical results confirmed the collected data from the survey were significant.
Journal of Construction Engineering and Project Management
/
v.4
no.3
/
pp.33-46
/
2014
Delay is the most common problem in the construction industry. It has many negative effects on project's success in terms of time, cost, quality, and safety. From the literature review, a total of thirty-five factors of delay were selected. These factors were divided into seven groups related to materials, manpower, owner, consultant, contractor, construction, and external problems. This study was carried out to identify the main causes of delay for a construction project through their importance level. The importance level was determined based on the frequency of occurrence and severity of impact. The structured questionnaire has distributed to the respondents who have much experience in construction management in Bangladesh. The results of analysis indicated that top five factors of construction delay according to their level of importance are: (1) price of construction materials increased very rapidly, (2) political situation (revolution/ public strikes), (3) shortages of skilled workers, (4) poor site management and supervision by contractor, (5) incompetent/ immature subcontractors. These findings of this study are expected to be significant contributions to Bangladesh construction industry in controlling current performance of project on time overrun.
Journal of Construction Engineering and Project Management
/
v.7
no.1
/
pp.1-12
/
2017
Construction delay is one of the basic constrains to achieve the project objectives in developing countries. This study aims to find the causes and effects of construction delays in developing countries. A thorough literature review has been done following the content analysis method. The relevant literature of 28 developing countries was collected from the scholarly journals published in the period of 2006 to 2016. The different developing countries are grouped into three geographic regions, i.e. South and Southeast Asia, Middle East, and Africa. In these regions, total 53 potential causes of delay under 8 major groups are identified. Frequency and ranking of these factors have been done. The factors, delay in progress payment by owner, contractors' cash flow problem, improper planning and scheduling, poor site management, and change order by owner during construction, are acknowledged as critical causes of delay in developing countries. This study will assist both academic and professional experts providing more insight about the construction delays and project management in developing countries.
Korean Journal of Construction Engineering and Management
/
v.20
no.6
/
pp.98-106
/
2019
Recently, the number of project delay-related claims and disputes in Korean construction projects has been increasing rapidly. This suggests that the domestic construction contract practice, which has traditionally been superior to the client, is changing into a mutually balanced relationship among the contracting parties. The project delay analysis selects the application method according to the type of schedule approved at the start of the construction and how the schedule management was performed during the construction. The most important prerequisite for project delay analysis is that a complete CPM schedule agreed at the beginning of the construction is prepared and the actual progress of such schedule is well documented. This study is about applying the project delay analysis methodology of a case where a contractor claims damages to a client while constructing a large new private building construction project. In this study, it is determined whether the application of the as-planned analysis method is appropriate to the incomplete CPM schedule and then proposes the as-planned vs. as-built analysis method based on the new standard as an alternative. Next, apply the as-planned vs. as-built analysis method to the schedule in the case project, and then compare it with the result of the as-planned analysis method. The purpose of this study is to suggest a project delay analysis method suitable for the domestic schedule management practices, so that it can be used as a meaningful reference in project delay disputes and litigations of domestic construction projects.
Park, Min Ha;Lee, Hye Lin;Ko, Yong-Ho;Han, SeungWoo
Proceedings of the Korean Institute of Building Construction Conference
/
2015.05a
/
pp.119-120
/
2015
Appropriate management of the finish works in construction project is one of most important activities that must be conducted considering the total duration of the project. Masonry work is a fundamental process that is performed in the preliminary steps of finish works. However, it has been investigated that the analysis of delay factors affecting masonry work has been neglected in the domestic construction site. Therefore, this study deducts delay factors affecting masonry work by literature review and survey on site engineers and labors. This study has been conducted as a preliminary step of developing a construction project interference management system which is expected to suggest objective information for the decision making in construction sites.
Luu, Van Truong;Kim, Soo-Yong;Pham, Nguyen-The-Thanh;Nguyen, Thanh-Long;Nguyen, Tuan-Kiet
International conference on construction engineering and project management
/
2015.10a
/
pp.104-108
/
2015
Delay on State-Funded Construction Projects (SFCPs) in Dong Thap - a province in Mekong Delta of Vietnam, as many provinces of Vietnam, have caused budget overrun through many recent years. The budget-overrun situations, in turn, have deepened the delay. Identifying critical factors affecting delay SFCPs plays a key role to mitigate negative impact of delay. 134/160 questionnaires were collected from personals working for project owners, consultants, supervisors and contractors in Dong Thap Province. Convenient sampling method was used. EFA was resulted in critical 04 factors with 20 variables caused delay in SFCPs, including: "Project technic, contractor's financial capacity and adjustment role of the government", "Regulation and Policy", "Mutual benefit support and concern between the government and residents", and "Disadvantage of construction site and weather season". Reliable measures to reduce delay on SFCPs are discussed to establish legal corridors to strictly controlling the process, consider mutual benefit between the government and its residents, and evaluating construction conditions. Those measures are considered could be applied in not only Dong Thap province, but most provinces of Vietnam as well.
Proceedings of the Korean Institute of Building Construction Conference
/
2010.05a
/
pp.125-129
/
2010
The ultimate goal of construction is to complete the given work in the most economical and safest way within the required construction period while meeting the quality standards specified in the design drawing. There are a few characteristics of finish work. First, executed in subdivided processes, finish work involves a very diverse and complex structure. Second, there are no criteria for each segmented process with regard to the appropriate time of input. Third, it is not very necessary to set priorities for lead and lag works. This study intends to provide information on the completion of a project in accordance with the required duration by setting priorities in the delay of each detailed process of finish work to minimize delay in finish work. In this study, finish work is divided into wet work and other types of finish work, and the importance of each process is classified based on the given details of each process. In addition, the study employs a survey to analyze delay factors of a designer, a constructor, and a supplier. Using the survey results, the study sets priorities in delay of final work to provide information on the completion of an apartment project within the planned construction period.
The purpose of this study is to find what factors are directly related to the delay of public projects, usually going beyond the planned deadline and budget. From a series of System Dynamics simulation works applied to the Cheongju Cremation Project, the research finds that the negative externalities originated from the adjacent location of the LULU(locally unwanted land use) facilities have exerted significant influence on dynamic perceptions of key stakeholders, typically resulting in project delay. As shown repeated experiments, the proposed negotiation-based models would produce relatively higher planning performance level than the typical approaches hinged on the administrative-expediency tactics. Even though the former may require more human and material resources in the very beginning stage, as they have to deal with diverse grievances raised by major stake-holders, most of them would bound for strengthening reinforcing loops within the complex structure. These results also imply that negotiation or consensus-building approaches would enhance mutual agreement among stake-holders, upgrading the overall quality of project management.
The purpose of this study is to find what causes make public projects hold off, going beyond the planned deadline and budget. Using System Dynamics(SD) and their derivative Urban Dynamics(UD) models, it intends to analyze major feedback loops based on VENSIM and to simulate them with STELLA software, all of which are interrelated with various causes of project delay. To prevent or ameliorate project delay, first of all it advises to focus on endogenous delaying factors not exogenous ones. These factors either reinforce or balance certain loops in complex causal structure, In the case example on the Cremation Building Project in Cheongju, Residents’ participation demand make negotiation put off and delayed negotiation reinforces administrative-expediency planning in order to observe a time limit, on the other hand, once building consensus, it increase both the level of planning performance and public trust. In the meantime, the real planning process used to neglect residents opinions and manage public grievance only through compensation, he a result of simulation, visible fruit of negotiation in the initial phase seems to be not satisfactory owing to funds and time consumed, but after reaching an mutual agreement among stakeholders, planning performance is effective and strategic than administrative-expediency planning viewed in both financial and time angle. It proposes to devise specific tools schematizing project implementation. In order to upgrade the quality of project management, it recommends for planners to adopt key concepts based on SD/UD diagrams and causal loops, which would contribute to enriching Planning abbots.
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.