• Journal of Arbitration Studies
• /
• v.32 no.4
• /
• pp.103-141
• /
• 2022

Traditionally, schedule analysis in Korea has been used, mainly through the Critical Path Method, to evaluate the claim for extension of time and/or the amount of liquidated damages for delay. Critical path method, however, cannot identify the delay event and its impact occurred in non-critical path especially in multi facility projects. In multi facility projects that comprise several independent but related facilities or structures, each facility has its own facility critical path the duration of which will be impacted by facility specific critical delays. Thus, only through the non-critical delay analysis along with the critical delay analysis damages not attributable to contractors may be remedied in full. Because all the records and pictures can reveal what has actually happened in post contract review, only the retrospective analysis rather than the prospective analysis based on the assumptions can establish the cause and allocate the each parties' responsibilities appropriately.

• Journal of Korean Academy of Nursing
• /
• v.28 no.1
• /
• pp.117-131
• /
• 1998

The purpose of this study was to develop a critical pathway for case management for patients who have received Coronary Artery Bypass Graft (CABG) because of Ischemic Heart Disease(IHD) which is a factor of rising medical expenses. For this study. a conceptual framework was developed through a review of the literature including six critical pathways which are currently being used in USA. In order to identify the overall service contents required by these patients and to draw up a preliminary critical pathway, 30 cases of medical records of patients who had CABG because of IHD between January, 1995 to June. 1996 at the Cardiovascular Center of Yonsei Medical Center in Seoul were analyzed. An expert validity test was done for the preliminary critical pathway and clinical validity test was also done using seven IHD patients with CABG between November 11 and 23, 1996. After these processes. the final critical pathway was developed. The results of this study are summarized as follows : 1. The vertical axis of the critical pathway includes the following eight items : tests, nutrition, medications, consultations, activity, assessments, treatments, education discharge planning and the horizontal axis includes the time from the start of hospitalization to discharge. 2. Analysis of the 30 medical records indicated that the average length of stay was 20.2days with the average length of stay from hospitalization day to operation day being 6.2 days, and the average length of stay from operation day to discharge day was 13. 9 days. Analysis of the service contents showed that the horizontal axis of the preliminary critical pathway was set from hospitalization to the 14th post operation day and the vertical axis was set to include eight items, the contents which ought to have occurred, according to the time frames of the horizontal axis. 3. As a result of the experts validity, it was found that among the total of 571 items. there was over 83% agreement for 482 items, less than 83% for 89 items, which were then deleted and a revision of the critical pathway was done. 4. A clinical validity test was done using seven IHD patients with CABG. During the process, three patients were deleted because they were out of the criteria the investigator set. Finally, four patients were used. The result of study indicated that only one patient was discharged on the tenth post operation day, which was one day later than the expected day. Three patients were discharged later than the expected day from three days to nine days. All the cases progressed on schedule until the operation day and the first post operation day, but from the second post operation days, there were differences between the critical pathway and the actual practice. The differences came from tests, assessments, and treatments. 5. On the basis of the results of the clinical validity test. the following revisions in the final critical pathway were made : the transfer from ICU to step down ward would be the second post operation day, and the transfer to a general ward, the fifth post operation day, for patients who complained of lack of sleep from the fifth post operation day to discharge, a sleeping pill would be prescribed, skin observations would be performed routinely from immediately after the operation until the third post operation day, and would continue if there was a sign of skin injury on the fourth post operation day, and assessment of chest pain would be done from the third post operation day, and the “stairs climbing” item, expected to be done on the ninth post operation day would be deleted. In conclusion, this critical pathway is partially applicable to the care of patients with CABG but there are some parts needed to be further investigated.

• Journal of Korean Critical Care Nursing
• /
• v.8 no.2
• /
• pp.55-65
• /
• 2015

Purpose: The purpose of this study was to identify the attributes, antecedents, and consequences of post-intensive care syndrome. Methods: The study was conducted in accordance with Walker and Avant's conceptual analysis process. We searched the Medline, ProQuest, Google scholar, NANET (Korean National Assembly Library), and RISS (Korean Education and Research Information Service) databases resulting in 29 studies for in-depth review. Results: The attributes of post-intensive care syndrome include (1) new or worsening impairment persisting after discharge, (2) physical impairment, (3) psychological impairment, (4) cognitive impairment, and (5) symptom experience. The antecedents of the concept include a critical condition that requires intensive care, stressful events, immobility, sedation, delirium, insomnia, frailty, and invasive procedures. The consequences of post-intensive care syndrome are increased dependency in activities of daily life, decreased social interaction, delayed return to previous occupation, decreased quality of life, familial post-intensive care syndrome, and readmission/death. Conclusion: The concept of post-intensive care syndrome has multifaceted and integrative features. Further research needs to be conducted to develop a measurement tool that reflects the attributes of the concept and to develop multidisciplinary interventions to prevent post-intensive care syndrome.

• Geomechanics and Engineering
• /
• v.28 no.5
• /
• pp.463-475
• /
• 2022

In the mine exploitation stage; one of the critical issues is the stability assessment of post-pillars. The instability of post-pillars leads to serious safety hazards in mining operations. The focus of this study is to assess the stability of post-pillars in the 130# stope in the central ore body at Trepça hard rock mine by employing both conventional (i.e., critical span curve) and numerical methods (i.e., FLAC3D). Moreover, a new numerical based index (i.e., Pillar Yield Ratio-PYR) was proposed. The aim of PYR index is to determine a border line between stable, potentially unstable, and failure state of post-pillars at a specific mine site. The critical value of pillar width to height ratio is 2.5 for deep production stopes (e.g., > 800 m). Results showed that pillar size, mining height and mining depth significantly have affected the post-pillar stability. The reliability of numerical based index (i.e., PYR) is verified based on empirical underground pillar stability graph developed by Lunder, 1994. The proposed pillar yield ratio index and pillar stability graph can be used as a design tool in new mining areas at Trepça hard rock mine and for other situations with similar geotechnical conditions.

• Structural Engineering and Mechanics
• /
• v.49 no.4
• /
• pp.427-448
• /
• 2014

At present, the time of easy oil and gas is over. Now, the largest part of fossil fuels is concentrated in the deepest levels of tectonic structures and in the sea shelves. One of the most cumbersome operations of their extraction is the bore-hole drilling. In connection with austere tectonic and climate conditions, their drivage every so often is associated with great and diversified technological difficulties causing emergencies on frequent occasions. As a rule, they are linked with drill string accidents. A key role in prediction of these situations should play methods of theoretical modelling. For this reason, there is a growing need for development and implementation of new numerical methods for computer simulation of critical and post-critical behavior of drill strings (DSs). In this paper, the processes of non-linear deforming of a DS in cylindrical cavity of a deep bore-hole are considered. On the basis of the theory of curvilinear flexible rods, non-linear constitutive differential equations are deduced. The effects of the longitudinal non-uniform preloading, action of torque and interaction between the DS and the bore-hole surface are taken into account. Owing to the use of curvilinear coordinates in the constraining cylindrical surface and a specially chosen concomitant reference frame, it became possible to separate the desired variables and to reduce the total order of the equation system. To solve it, the method of continuation the solution by parameter and the transfer matrix technique are applied. As a result of the completed numerical analysis, the critical states of the DS loading in the cylindrical channels of inclined bore-holes are found. It is shown that the modes of the post-critical deforming of the DS are associated with its irregular spiral curving prevailing in the zone of bottom-hole-assembly. The possibility of invariant state generation during post-critical deforming is established, condition of its bifurcation is formulated. It is shown that infinite variety of loads can correspond to one geometrical configuration of the DS. They differ each from other by contact force functions.

• Korean journal of food and cookery science
• /
• v.2 no.2
• /
• pp.76-83
• /
• 1986

Time and temperature, pH and Aw, and microbiological evaluation were made to identify critical control points during various phases in product flow of chicken soup preparation in a university foodservice establishment. The results are summarised as follows: 1) Time and temperature data indicated that the phases of cooling after cooking, post-preparation, and holding ingredients at room temperature before assembly were critical. 2) pH and Aw values were in favorable for microbial growth. 3) Microbiological data indicated that the phases of basic ingredients. post-preparation and holding ingredients before assembly were critical. 4) Critical control points identified were; basic ingredients, cooling after cooking, post-preparation, holding before assembly and service, and assembly and service. 5) Several guidelines were suggested for the effective qualitly control program.

• Nuclear Engineering and Technology
• /
• v.47 no.4
• /
• pp.407-415
• /
• 2015

A developing post-dryout region is characterized by significant heat transfer enhancements compared with the fully developed post-dryout region. The heat transfer enhancements are mainly due to upstream disturbance and entrained droplets in the region immediately downstream of the critical heat flux location. In this paper, an improved heat transfer correlation is developed for the developing post-dryout regions in vertical tubes over a wide range of flow conditions. The correlation represents a correction factor for the fully developed film-boiling look-up table to be applied to the developing post-dryout region. The new correlation significantly improves the heat transfer prediction in the developing post-dryout regions and provides very good agreement with the experimental data.

• 한국공간정보시스템학회:학술대회논문집
• /
• 2004.05a
• /
• pp.37-42
• /
• 2004

The primary objective of this paper is to trace the post-buckling behavior of space trusses in the inelastic range. Modeled member material behavior characteristics of struts in the post-critical elasto-plastic stage are determined and three types of idealized hardening rules are described. To perform this analysis, the present work is used the current stiffness parameter method combined with the cylinderical arc-length method. Numerical examples are presented to illustrate the accuracy and the application of the numerical solutions introduced above.

• Journal of Electrical Engineering and Technology
• /
• v.8 no.2
• /
• pp.197-205
• /
• 2013

Real time transient stability assessment mainly depends on real-time prediction. Unfortunately, conventional techniques based on offline analysis are too slow and unreliable in complex power systems. Hence, fast and reliable stability prediction methods and simple stability criterions must be developed for real time purposes. In this paper, two new methods for real time determining critical clearing time based on clustering identification are proposed. This article is covering three main sections: (i) clustering generators and recognizing critical group; (ii) replacing the multi-machine system by a two-machine dynamic equivalent and eventually, to a one-machine-infinite-bus system; (iii) presenting a new method to predict post-fault trajectory and two simple algorithms for calculating critical clearing time, respectively established upon two different transient stability criterions. The performance is expected to figure out critical clearing time within 100ms-150ms and with an acceptable accuracy.

• Journal of Dental Anesthesia and Pain Medicine
• /
• v.19 no.1
• /
• pp.73-75
• /
• 2019