The 9th International Conference on Construction Engineering and Project Management
/
pp.213-221
/
2022
Defects are the risk factors in the construction process of buildings. They cause damage, delaying the construction duration. They especially cause adverse effects on the top-down construction method. This study analyzed the degree of construction delay induced by each work type, focusing on defects in the top-down method. Then, we derived construction delay induction coefficient from different work types in order by using the severity of construction delay per defect and the occurrence probability of defect; this assessment model measures the impact of defects on construction delay for each work type. Furthermore, by comparing each work type based on the defect frequency and the construction delay induction coefficient, we found work types that need to be administered attentively. We identified that plastering work was easy to overlook, requiring caution in defect management. This study provides an efficient defect management system suitable for the buildings that are built using the top-down construction method.
The performance of the construction project is to be evaluated within 60 days of completion, according to relevant laws. It evaluates cost, construction period, design change, re-construction, safety, etc. for each project stage. And the project owners are inputting the evaluation results of the construction work into the construction project information system(CALS). The post-evaluation result information entered in this way can be referred to in the basic design of the construction project by referring to the related contents if there is a similar construction in the future. And It can also be used to predict and respond to the required period and cost by analyzing the accumulated data. In this study, in order to provide reference data that can be used in similar projects in the future, the latest analysis methods are reviewed and the possibility of future application is considered. Accordingly, this study intends to focus on the construction cost part among the indicators such as construction cost, construction period, design change, and re-construction that are currently being dealt with in post evaluation.
According to relevant laws, in the case of a construction project with a total construction cost of 30 billion won or more, a post-construction evaluation must be performed after completion. In addition, a post-construction evaluation report must be prepared and entered into the Continuous Acquisition & Life-cycle Support(CALS). As a result of reviewing the currently accumulated post-construction evaluation reports, since the report is not standardized, it is difficult for public project owners to write the report. It also hinders the post-construction evaluation and management center from verifying contents, analyzing data, and deriving meaningful results. In order to improve the convenience of the public owners who must conduct post-construction evaluations and the work efficiency of the center, evaluation factors were standardized and a standard post-construction evaluation report format for road construction was developed in Excel. Through this, the data in the reports will be effectively accumulated, managed, and analyzed, so that meaningful results will be produced and be helpful in future construction work.
As the construction industry has been increasingly complex, aging workers, hard-working avoiding young generation, foreign workers having language problem for the past decades, delivering of construction qualified workers has been a rising problem. This misalignment between the complex jobs and the number of skilled workers will continue to be in issue that the construction industry will face for following decades. Construction field workers who are working outside in uncontrollable condition unlike manufacturing industry are exposed to easily construction safety accident. There are so many efforts to prevent and control the construction accident. However, the relationships between the construction works and construction safety accident has not been well dealt and investigated based on objective accident data except for the qualitative study through interview, delphi and so on. Therefore this study analyzes job risk matrix exposed to safety accidents based on statistic data for 20 years from Korean Occupational Safety & Health Agency in order to prevent the construction field accidents.
The 6th International Conference on Construction Engineering and Project Management
/
pp.604-605
/
2015
To secure quality of dam construction needs appropriate construction duration. Tight construction schedule may have negative influence on infrastructure quality, work safety and maintenance cost. It is necessary to reflect proper construction duration in the planning phase. There have been standards for estimating construction duration of building and industrial complex development but dam construction have not. In order to estimate construction duration of CFRD, feasible study reports and design reports were analyzed to acquire available information. After that, considering on construction duration methods such as comparison with similar cases, approximate estimating formula, approximate quantity assumption were adapted to Critical Path items. Hence, this study present framework for construction duration estimating of CFRD in the planning phase. This framework can be applied other types of dam along the same line.
Climate change caused by greenhouse gas emissions has become a climate crisis that actually threatens us and is making global efforts to solve it. In response, Korea is carrying out a "Green remodeling" project to reduce carbon emissions generated in the building maintenance stage, which has the highest percentage of all carbon emissions. However, Green remodeling is carried out under emergency supervision at the construction stage, but construction supervisors are often non-professionals, and even experienced site directors have difficulty in implementing actual designs if they do not have experience in Green remodeling construction. Therefore, this study aims to derive priorities between construction and construction focus points for each construction in order to standardize the construction of Green remodeling construction works and derive objective guidelines.
Research on construction waste unit was in progress in the 1995 when 'Proper Disposal and Recycling Measures for Construction Waste' was made by the Seoul Development Institute. Such an effort has been made in order to cope with the lack of natural resources in Korea and to utilize the reusable resources. Furthermore, these efforts have also increased due to the improved standing of Korea in the international community. A large number of residential buildings were built in the response to the government's policy by increasing the supply of houses between the 1970's and 1980's. In 2000, more reconstruction and redevelopment was done because of the aged buildings and change of use for those buildings. And the project has been actively promoted until now, which caused a sharp increase in the generation volume of construction waste. In Korea, 8 kinds of construction waste unit, including the standard construction manpower and materials estimation, are introduced. Currently, they provide standards to different building categories and waste properties while for construction sites different standards are applied. This study aims to measure the actual amount of construction waste after sample buildings are dismantled and analyzes the estimation of the waste quantity by using various standard units. Through comparison, this study will figure out the differences among the standard units in order to find out how to apply the standard units properly. Moreover, this research will provide practical measures to apply such units to construction sites.
With improvements of information technology, the cases which automation technology are applied to construction site are increased. These technologies have advantages and limitations for construction site, therefore they has to be considered in order to maximize benefit. This study are to suggest the process for optimizing management of steel framing high-rise building construction.
The 6th International Conference on Construction Engineering and Project Management
/
pp.721-722
/
2015
The aim of this research is to provide a direction to benchmark advanced construction companies from Spain and France by deriving business strategies through SWOT analysis in order to strengthen overseas expansion and competitiveness of domestic construction companies.
국내 기업의 해외 건설 수주는 지속적으로 성장하고 양적성장을 이루어왔지만, 2011년 유가하락에 이어 최근 COVID-19의 장기화 등 대외환경의 불확실성이 커지며 해외 건설 시장의 침체가 전망된다. 이에 4차 산업혁명의 발전된 기술을 활용해 그간 축적된 데이터를 연구한다면, 향후 해외 건설사업 관리의 역량 및 경쟁력을 키울 수 있을 것이다. 따라서 이 연구에서는 중동 건설시장에서 공정지연과 주요 분쟁의 원인으로 대두되고 있는 공사변경의 상향된 프로젝트 관리 방안을 제시하고자 하였다. 우선 실제 해외 플랜트 건설사례를 분석하여 6가지 주요 공사변경 원인을 도출하였고, 이에 따라 영향을 받는 요인을 8가지로 분류하였다. 특히 머신러닝 기반의 다양한 Feature Selection 기법을 활용해 중요도를 계량화된 수치를 평가함으로써 공사변경과 영향 요인 사이의 유의미한 관계를 파악 하였다. 이를 통해 프로젝트 관리 측면에서 내부적으로는 공사변경의 명확한 관리 방향 수립이 가능하고, 대외적으로는 협상 기간 단축으로 추가적인 공기 지연을 방지하고 비용지출 관리가 가능할 것이라고 판단된다.
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.