• Korean Journal of Construction Engineering and Management
• /
• v.8 no.1 s.35
• /
• pp.78-86
• /
• 2007

Top priority to manage construction projects is given to the planning and scheduling in order to keep the project duration, which is one of the most important factors in construction management. However, recently most of public construction projects especially for civil projects are delays and preventive research, many efforts were made concerning construction delays and preventive management methods. But analysis of delay causation, which is a main key to solve the problems is not done, yet. Therefore, in this research causation delays are analyzed by characteristics of construction projects, which are type of projects, type of contracts, project participants, and general condition. As a result of the analysis, delay causation are proved to be different by characteristics of the projects. The research results will be used for prevention of time extension and dispute resolution.

• Journal of Construction Engineering and Project Management
• /
• v.2 no.3
• /
• pp.17-29
• /
• 2012

Delays are one of the biggest problems facing by the construction industry and they have significant financial and social impact in construction projects. The paper presents a framework of Delay Analysis System (DAS) with the aim of analysing the impact of delay factors in Libyan construction projects. The system has designed by integrating the possible delay factors, critical activities of a project using@risk simulator. A case study of building project was demonstrated to identify the impact of delays and the sensitivity of delay factor. The case study result showed that the project might be delayed by 97 to 103 days in comparison to the planned duration. The developed DAS is a tool for analysing and identify the impacts of delay factors and assist to construction manager to take necessary measure in reducing the delay impact. The paper provides a methodology for analysing the possible delay impact in a construction project and informing to construction manager in advance of the possible delay factors.

• International conference on construction engineering and project management
• /
• 2007.03a
• /
• pp.520-529
• /
• 2007

Apportioning responsibilities of concurrent delay to the owner and the contractor is a difficult task, due to the sophisticate nature both in the schedule and in the factors that cause the delay. This research attempts to develop a simplified yet systematic approach that can be used for a fair apportionment of concurrent delay. A concurrent delay is defined herein as when the contractor and the owner have both caused independent critical path delays during the same approximate time period. Incorporating the concepts of windows analysis and critical path method (CPM), the developed approach has three "windowing of delay" steps to quickly apportion the delay in each of these windows, and a fourth step to sum up those apportioned delays to obtain each party's final responsibilities. This developed approach is found to be simple and effective at this stage; it will be tested against real cases in the near future.

• International conference on construction engineering and project management
• /
• 2015.10a
• /
• pp.599-599
• /
• 2015

This research attempts to resolve the construction delay issues of indirect delays by developing the "Delay Responsibility Determination Model" (DRM) based on probabilistic risk analysis. DRM is envisioned to provide a way of quantitatively analyzing impacts of delayed activities while considering both direct and indirect influences. With the successful development of DRM, it would be possible to present relative probabilistic measures to all the related stakeholders in terms of their contributions to schedule delays. Upon the development completion of DRM, "Korean Construction Delay Claim/Dispute Resolution Protocols" will also be prepared to facilitate the effective use of DRM.

• International conference on construction engineering and project management
• /
• 2011.02a
• /
• pp.614-620
• /
• 2011

Delays in completing construction projects have significant financial and social impact to all parties involved in the construction process and in particular in developing countries. This is very evident in most construction projects in Libya and in both public and private sectors. The research study was initiated by Libyan Government and the main aim of the project is to develop a new strategy in reducing the impact of delay factors. In order to achieve this, a number of objectives have been set-to conduct a comprehensive literature survey, to conduct a comparative study of the delay factors in project completion in both Libya and UK using semi structured questionnaire and finally, to identify and analyse the causes of delay and ranked them using frequency of occurrence and severity. The critical causes of delay for construction projects were quite different between Libya and UK. For the former, the most critical causes of delay in Libyan construction industry were low skills of manpower, changes in the scope of the project, slowness in giving instruction and poor qualification of consultant, while for the latter they were financial problems, bad weather conditions on the job site and change in the scope of project. Statistical experiments including Paired Samples T-Test, was run to test the significance of the survey data in both countries Libya and UK. The statistical results confirmed the collected data from the survey were significant.

• International conference on construction engineering and project management
• /
• 2015.10a
• /
• pp.161-165
• /
• 2015

The delay in construction is the challenge often faced in the course of executing construction projects. To the government projects, the delays become very serious. This problem directly affects the lives, social welfare of the people, and the other negative social impacts. However, the government projects have not been much interest. The questionnaire surveys in Vietnam were conducted to determine the causes of the delay and to find solutions for dealing with the delay. The average index was used to rank the delay factors and the solutions. This study identified the 5 most highly ranked delay factors and the 8 best solutions from a list of 31 delay factors and 19 solutions for the delay. The five most highly ranked delay factors were: information delays and lack of information exchange between the parties; incompetent owner; incompetent supervision consultant; incompetent contractor; and difficulties in financing project by owner. The findings of the study can help the parties involved the government construction projects and practitioners to give appropriate strategies for countering the delay in their projects.

• Nuclear Engineering and Technology
• /
• v.51 no.2
• /
• pp.618-625
• /
• 2019

When newcomer countries consider a nuclear power programme, it is recognized that the most important organizations are the Nuclear Energy Programme Implementing Organization (NEPIO), the regulator, and an operating organization. Concerning the number of construction delays these days, one of the essential organizations is an Authorized Inspection Agency (AIA). According to World Nuclear Industry Status Report, all of the reactors under construction in eight out of the thirteen countries have experienced delays. Globally, the Flamanville 3 project and Sanmen Unit 1 are 6.5 years and 5 years late respectively. One of the major reasons of delay is due to inappropriate manufacturing and inspection on safety class components. The recommendations are made to develop such an organization: (i) find existing inspection organizations in relevant industries, (ii) contract with expatriates who have experience on nuclear inspection, (iii) develop a legislative framework to authorize the inspection organization with enforcement, (iv) include a contract clause in the BIS for developing the AIA, (v) hold training programmes from vendor country, (vi) during manufacturing and construction, domestic AIA shall be involved.

• KSCE Journal of Civil and Environmental Engineering Research
• /
• v.43 no.6
• /
• pp.841-849
• /
• 2023

Construction projects have risks due to various factors such as construction delays and construction accidents. Based on these construction risks, the method of calculating the construction period of the construction project is mainly made by subjective judgment that relies on supervisor experience. In addition, unreasonable shortening construction to meet construction project schedules delayed by construction delays and construction disasters causes negative consequences such as poor construction, and economic losses are caused by the absence of infrastructure due to delayed schedules. Data-based scientific approaches and statistical analysis are needed to solve the risks of such construction projects. Data collected in actual construction projects is stored in unstructured text, so to apply data-based risks, data pre-processing involves a lot of manpower and cost, so basic data through a data classification model using text mining is required. Therefore, in this study, a document-based data generation classification model for risk management was developed through a data classification model based on SVM (Support Vector Machine) by collecting construction project documents and utilizing text mining. Through quantitative analysis through future research results, it is expected that risk management will be possible by being used as efficient and objective basic data for construction project process management.

• Proceedings of the Korean Society for Noise and Vibration Engineering Conference
• /
• 2008.04a
• /
• pp.879-881
• /
• 2008

The construction noise and vibration is a serious social problem in the downtown. This results in many expenses and delays of construction process because of the satisfactory settlement of popular complaints. In this study, we analyze the dispute mediation cases on the damages of construction noise and vibration and the noise and vibration condition in construction sites by using questionnaire surveys.

• Journal of Construction Engineering and Project Management
• /
• v.7 no.1
• /
• pp.13-25
• /
• 2017

Construction projects have been observed to have problems of project delays and disruptions and the South African construction industry is not an exception. This research identified causes and effects of project delay and disruption through a desktop study. Subsequently, a questionnaire was designed and used to conduct a survey to obtain the views of the three main construction project participants - clients, consultants, and contractors. The questionnaire contains 48 causes and 13 effects of project delay and disruption identified from the desktop study. This research identified sixteen most important causes of project delay and disruption and five most important effects of delay and disruption. Sixteen most important causes were: (1) strikes, (2) rework due to errors during construction, (3) shortage of materials in market, (4) suspension of work by the client, (5) poor communication between the parties, (6) ineffective planning and scheduling of project, (7) delays in issuing working drawings, (8) mistakes and discrepancies in design documents, (9) shortage of labours and equipment, (10) delay in decision making process by the client, (11) unforeseen ground conditions, (12) unclear and inadequate details in drawing, (13) inadequate contractor's experience, (14) delay in approving changes in the scope of works, (15) delay in material delivery and (16) unacceptable quality of materials. The five major effects include: (1) create stress on contractors, (2) cost overrun, (3) time overrun, (4) poor quality of work due to rush, and (5) disputes. Furthermore, the result of this research was compared with the result of previous studies conducted in other regions of Africa in terms of causes and effects of project delay and disruption. The research concludes that numerous causes and effects of delay and disruption are limited to South African construction projects based on the comparison. The causes limited to South African construction projects include: (1) strikes, (2) suspension of work by the client (3) mistakes and discrepancies in design documents (4) delay in approving changes in the scope of works and (5) unacceptable quality of materials, while the two major effects limited to South African construction projects includes: (1) create stress on contractors and (2) poor quality of work. In conclusion, some recommendations were made in order to minimise the causes of delay and disruption identified.