Construction schedule plays a key role in project management due to its influence on the project success. Thus, it is important to identify factors affecting construction delay. The major objective of this study is to identify and evaluate factors affecting construction delay in apartment projects in Vietnam. The findings confirmed that financial difficulties of owners and contractors, contractors without adequate experience, non-available materials on time, slow site clearance, inappropriate construction methods, defective works and reworks, and lack of capable owners/project managers are the major causes of delay in apartment projects.
The purpose of this paper was to explore delay avoiding measures and strategies. The paper was based on previous work of authors on finding delay causes. Firstly, the paper has discussed about delay avoidance measures prescribed by the previous work. As the previous study identified five main causes of construction delays, various measures and strategies to overcome those delay problems have been discussed in sequence in the last sections. Major delay prevention strategies are: involving stakeholders in the project decisions, outreach program, realistic time and resource estimation, try to adjust the triple constraints of time, cost and scope, ensure fair and complete disclosure of information at an early stage of the construction project, contractor, itself should inquire about patent design errors prior to submitting its bid, owner should include in its contract with the consultant an indemnity (protection) clause etc.
In this work, the delay time for groundwater recharge was estimated by comparing simulated recharges by means of SWAT(Soil and Water Assessment Tool) model and WTF(Water Table Fluctuation) method. The delay time for groundwater recharge means that the time when the water from rainfall travelled through vadose zone just after getting out of soil zone bottom. As measuring this delay time is almost impossible, we used to compare the estimated values from modeling(SWAT) and analytic method(WTF). The test site is Hancheon watershed which has 8 groundwater measurement stations. The results show that the altitude has a linear relationship with the estimated delay time values. To validate these results, we conducted corelation analysis between transformed groundwater levels and observed ones. The results showed that computed groundwater levels have good corelation($R^2$=0.97, 0.87, respectively). The estimated delay time would be used for the groundwater behaviour characteristics in vadose zone. As recharge rates vary according to the height, the delay time is thought to be an import variable for the proper groundwater recharge estimation.
Journal of Construction Engineering and Project Management
/
제4권3호
/
pp.33-46
/
2014
Delay is the most common problem in the construction industry. It has many negative effects on project's success in terms of time, cost, quality, and safety. From the literature review, a total of thirty-five factors of delay were selected. These factors were divided into seven groups related to materials, manpower, owner, consultant, contractor, construction, and external problems. This study was carried out to identify the main causes of delay for a construction project through their importance level. The importance level was determined based on the frequency of occurrence and severity of impact. The structured questionnaire has distributed to the respondents who have much experience in construction management in Bangladesh. The results of analysis indicated that top five factors of construction delay according to their level of importance are: (1) price of construction materials increased very rapidly, (2) political situation (revolution/ public strikes), (3) shortages of skilled workers, (4) poor site management and supervision by contractor, (5) incompetent/ immature subcontractors. These findings of this study are expected to be significant contributions to Bangladesh construction industry in controlling current performance of project on time overrun.
In order to reduce the construction cost and period without degrading the quality, construction companies are making a lot of efforts to prefabricate and mechanize the construction process, and introducing and utilizing various techniques of construction time management in the process of construction. However, due to the various factors (such as weather conditions, labor factors, supply of equipment and materials, safety accident, etc) in the process of construction, construction projects are not frequently completed within the scheduled Period. This research is to examine the current status of construction time management and factors causing delay in construction with regard to the concrete work (such as form work, steel reinforcement, and concrete work) in building apartments.
건설공사는 프로젝트의 진행 중 내${\cdot}$외부의 여러 조건의 변경이나 사회적 요구에 따라 초기의 계약과는 다른 많은 변경사항이 발생하게 된다. 이러한 변경사항은 프로젝트 추진과정에서 많은 영향을 미치게 되며, 이로 인하여 발생되는 영향은 대부분 프로젝트의 공기지연으로 나타나게 된다. 건설공사에서 발생하는 공기 지연은 기본적으로 도급자의 면책여부에 따라 공기연장이나 지체상금의 부과 등의 결과로 나타나게 되는데 이러한 사항에 대한 발주자와 도급자의 의견이 대립될 경우 클레임으로 발전하게 된다. 클레임에서 가장 중요한 사항은 공기지연일수의 산정으로서 이는 공기지연 클레임에서 가장 중요한 부분이라고 할 수 있다. 본 연구에서는 공기지연 클레임에서 가장 중요한 자료가 되는 공기지연일수 산정방법의 한 방법으로 계약 초기에 작성된 계획공정표(As-Planned Schedule)와 모든 지연이 포함된 준공공정표(As-Built Schedule including all delays) 그리고 발주자 지연이 제외된 준공공정표(As-Built schedule absent owner delays)를 비교함으로써 각 계약 구성원의 귀책으로 인한 광기 지연일수 산정방법을 제시하고자 한다.
최근 공공공사에서 공기지연은 지속적으로 발생하고 있으나 책임 미 이행으로 인하여 당사자의 손해 발생은 물론 클레임 및 분쟁으로 비화될 가능성이 점차 커지고 있다. 이는 현행 공정관리가 책임구분이 불가능한 문제점을 내포하고 있어 공기지연이 반복적으로 발생되며, 당사자의 책임이행도 불가능하게 만들고 있기 때문이다. 따라서 공기지연의 반복적 발생을 예방하고 공기지연에 대한 당사자의 능동적 책임이행을 위하여 책임구분이 가능한 공기지연관리 방안의 마련이 매우 필요한 실정이다. 이러한 관점에서 본 연구는 건설현장에서 쉽게 활용할 수 있는 지연사유에 대한 사전적 관리 개념을 도입한 공기지연 사유 관리 모델을 제시하였다. 제시한 모델은 첫째, Cell 개념의 사유 세분화 및 계층화를 통한 사유의 근본 원인을 파악하기 용이하게 하였으며, 둘째, 발주자, 시공자, 제3자로 업무 수행 절차를 구분함으로써 지연사유를 명확하게 구분할 수 있게 하였다. 셋째, Matching 시스템을 통한 사유, 일수 및 해당근거를 연계함으로써 클레임에 대한 명확성을 제시할 수 있도록 하였다.
The 2th International Conference on Construction Engineering and Project Management
/
pp.520-529
/
2007
Apportioning responsibilities of concurrent delay to the owner and the contractor is a difficult task, due to the sophisticate nature both in the schedule and in the factors that cause the delay. This research attempts to develop a simplified yet systematic approach that can be used for a fair apportionment of concurrent delay. A concurrent delay is defined herein as when the contractor and the owner have both caused independent critical path delays during the same approximate time period. Incorporating the concepts of windows analysis and critical path method (CPM), the developed approach has three "windowing of delay" steps to quickly apportion the delay in each of these windows, and a fourth step to sum up those apportioned delays to obtain each party's final responsibilities. This developed approach is found to be simple and effective at this stage; it will be tested against real cases in the near future.
The links operating interrupted flow are intend to yield the traffic between the out flow and inflow part effect zone of street section, we build the delay model using the time gap between under construction and not. We review the applicability of interrupted flow, and thus we can put this data to practical use as the basis data to compute the inducement charge for traffic delay. Also building about traffic effect zone of interrupted flow wouldn't produce at the section beside occupying roads and construction cross section, thus we must review the plan to minimize traffic delay by the construction occupying road. In future there must be advanced the incomplete in this study, and groping for the various alternatives to minimize the traffic delay by the road occupying construction, with developing the various sets of detailed analyzing models, that is analysis on the street strength, crossroads geometrical forms of crossroads, public traffics, pedestrians, occupying types.
Construction projects are facing delay problems. Delays in construction have been immense effect on performance or satisfactory delivery of the project. Delays have been causing project cost overrun as well as it is a source of dispute hence damaging the relationship between the project participants. The purpose of this study was to explore the causes of delay risk through a field survey study. Data were collected from construction professionals working in owner, consultant and contractor organizations. All together 208 questionnaire instruments were used and analyzed by employing statistical tools (SPSS computer program). 19 delay factors were identified by this study, out of which following factors were critical: Frequent interruptions from public (local people, pressure group etc.), changed site condition, failure to provide required construction site, unrealistic project time estimation and design errors.
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.