• International conference on construction engineering and project management
• /
• 2007.03a
• /
• pp.520-529
• /
• 2007

Apportioning responsibilities of concurrent delay to the owner and the contractor is a difficult task, due to the sophisticate nature both in the schedule and in the factors that cause the delay. This research attempts to develop a simplified yet systematic approach that can be used for a fair apportionment of concurrent delay. A concurrent delay is defined herein as when the contractor and the owner have both caused independent critical path delays during the same approximate time period. Incorporating the concepts of windows analysis and critical path method (CPM), the developed approach has three "windowing of delay" steps to quickly apportion the delay in each of these windows, and a fourth step to sum up those apportioned delays to obtain each party's final responsibilities. This developed approach is found to be simple and effective at this stage; it will be tested against real cases in the near future.

• International conference on construction engineering and project management
• /
• 2005.10a
• /
• pp.360-365
• /
• 2005

The need of constructing high-tech facilities is one of the important issues concerning the competitiveness by the high-tech companies. It, simultaneously, offers a magnificent opportunity for construction participants. Nevertheless, the high-tech construction is experience-based, resulting in little related construction knowledge that has been statistically analyzed and documented. This study measures and confers with the profit patterns causing the disparity between the traditional and high-tech construction. The database was the result of collecting detailed information of 65 construction projects from eight construction companies, including detailed records of over 20 main construction operations in each project. All of these were performed during the recent 10 years and encompassed in the project types of the high-tech construction, residential building, and commercial building. Rendering suggestions regarding profit management and expecting to economize cost of learning from inexperience while extending to the high-tech construction were both presented.

• International conference on construction engineering and project management
• /
• 2011.02a
• /
• pp.357-363
• /
• 2011

Mediation has long been praised as one of effective dispute resolution methods in the area of construction law. Article 85-1 of the Taiwan Government Procurement Act was amended and promulgated by presidential decree on July 4, 2007. The second paragraph of the Article elaborates explicitly, "In the event that the application for mediation referred to in the preceding paragraph is made by the supplier, the agency may not object to such application." Beyond that, if an unsuccessful mediation of a construction dispute is due to the agency's disagreeing with the proposal or resolution for mediation proposed by the Complaint Review Board for Government Procurement ("CRBGP"), the agency may not object to the arbitration filed by the supplier. It undoubtedly reinforces the importance of the mediation-arbitration procedure. Accordingly, this paper elaborates on the mediation mechanism in Taiwan in the framework of construction disputes first. After that, dispute resolution of a local public work case is provided to demonstrate the practice of construction mediation in Taiwan. Lastly, this study proposes suggestions on applying mediation to ease similar subsequent cases.

• The Journal of Economics, Marketing and Management
• /
• v.5 no.2
• /
• pp.1-9
• /
• 2017

This study has reviewed the "A survey on the relation between the employees' viewpoint with knowledge management and cultural intelligence among the employees working in Social Security Organization of Ardabil". The present study is functional in terms of objective and the method is descriptive and survey. This has asked the others' ideas and viewpoints concerning a specific subject and has analyzed them. About the nature and the method used, the present research is of correlation research. The population applied in this research includes all employees working in Social Security Organization of Ardabil consisting of 400. The method used for sampling is simple random sampling. To collect the information in the first step of the research the library method has been used. In this research the data has been collected through standard questionnaires. Then, via descriptive and inferential statistics the research data has been characterized and regarding the spatial scaling of the measurement to test the hypothesis the, correlation analysis of Pearson has been used and also to specify the reliability of the questionnaire the Chronbach's Alpha has been taken in use and the SPSS software to analyze the data also. The findings resulted from the study showed that there is a significant relation between the factors concerning employees' efficiency with knowledge management and the cultural intelligence and all hypotheses was confirmed.

• Journal of Contemporary Eastern Asia
• /
• v.16 no.1
• /
• pp.93-113
• /
• 2017

This study aimed to determine the changes in the local fiscal structure brought about by the change in the transaction tax, including the acquisition tax, by the central government. The review of the analysis results proved the following. First, the government's transaction tax exemption policy effectively influenced the expansion of the local fiscal budget. Transaction tax exemptions such as acquisition tax exemptions would not contribute to the expansion of the local fiscal budget in the short run, but may do so in the long run. Second, the review of the effect of the transaction tax exemption policy by the central government on the local fiscal structure confirmed that its impact on the local fiscal structure may vary depending on the timing of such tax exemption. Third, the overall local fiscal structure as a result of the transaction tax exemption by the central government was confirmed to have been influenced more by the fiscal capability of the local government than by the income level of the local residents. In conclusion, the stimulation of real estate transactions using tax tools may positively influence the overall fiscal structure of local governments, but it would also put pressure on the fiscal management of local governments because it is largely influenced by the fiscal capability of the local governments.

• Journal of Korean Society of Transportation
• /
• v.5 no.2
• /
• pp.81-95
• /
• 1987

In line with the continued growth of car ownership, the traffic problems in central area of metropoles such as Seoul would become increasingly degraded. comparing with most western cities, the problems in Seoul are characterized by the improportionately high rates of intersection delay, station congestion, traffic accidents caused by weaving conflicts and pedestrian congestion. It is caused by the lack of flexibility I street network, which is prerequisite for upholding the efficacy of traffic management and control, resulted from the simplicity of network graph in terms of connectivity, street density and distribution by width. This pattern has been resulted from the prolonged policy pursuing the street-widening of the nagging bottleneck in such a short period since the 1950s, comparing that most western cities had undergone over several centuries an age of horse-and-vehicle transportation. In order to improve the expected traffic problems in central area over the coming periods of motorization, it is imperative to restructure the street network in Central Seoul so that the efficacy of traffic management and control may be operative. Based upon the long-range planning the street network should be restructured by stages so that cenral traffic may be controled by one-way operation and most through-traffic be detoured around fringe area.

• International Journal of Industrial Entomology and Biomaterials
• /
• v.7 no.2
• /
• pp.93-106
• /
• 2003

Soilborne diseases pose a serious problem for mulberry cultivation during nursery plantation and established gardens, which cause severe loss in revenue generation of mulberry growers as compared to foliar diseases. Various soilborne diseases affect mulberry. Among them, root knot and root rot affect the established plantation resulting in severe loss in leaf yield apart from deterioration in leaf quality, which is a pre-requisite in successful sericulture to get the good quality of cocoons. Besides, stem-canker, cutting rot, collar rot and die-back, affect the initial establishment and survivability of mulberry plantation in nursery. The problem is difficult to handle, due to the complex nature of the diseases and also involvement of various biotic and abiotic factors. This is compounded by the occurrence of disease complex (especially nematode ＋ soilborne pathogenic microbes) in established mulberry gardens, which facilitates quick spread of the disease and enhance the plant mortality, resulting substantial loss in leaf yield. Therefore, prevention and timely control measures need to be taken up to protect the mulberry plants from different soilborne plant pathogens. In this review article, symptomatology, epidemiology, disease cycle and control measures of soilborne diseases of mulberry are discussed.

• KSII Transactions on Internet and Information Systems (TIIS)
• /
• v.15 no.6
• /
• pp.2031-2048
• /
• 2021

Not only can air pollution reduce the overall competitiveness of tourist destinations, but also changes tourists' travel decisions, thereby affecting the tourism flows. The study presents a machine learning method to analyze how the haze pollution puts spatial effect on tourism flows in China from 2001 to 2018, and reveals the regional differences in heterogeneity among eastern, central, and western China. Our investigation reveals three interesting observations. First, the Environmental Kuznets Curve of the impact of haze pollution on tourism flows is not significant. In the eastern and western regions, the interaction between haze pollution and domestic tourism flows as well as inbound tourism flows shows an inverted U-shaped curve respectively. Second, there is an significantly positive spillover effect of tourism flows in all of the eastern, central, and western regions. As to the intensity of spillover, domestic tourism flows is higher than that of the inbound tourism flows. Both of the above figures are greatest in the eastern. Third, the Chinese haze pollution mainly reduces the inbound tourism flows, and only imposes significantly negative direct effects on the domestic tourism flows in the central region. In the central and eastern regions, significantly negative direct effects and spillover effects are exerted on inbound tourism.

• International conference on construction engineering and project management
• /
• 2022.06a
• /
• pp.401-407
• /
• 2022

Central heating, ventilation and air conditioning (HVAC) is one of the largest consumers of energy in the residential sector. This project explores the use of multiple HVAC units and/or Zoning in a single residence to reduce energy loads. The energy consumption data of a detached single-family home using two HVAC units, one primary for the main house and a secondary HVAC for a casita, was collected for the same month for two consecutive years, along with details related to the outdoor temperature and the square footage being air-conditioned by each HVAC. A regression algorithm was trained using the above details to find the relation between the parameters. Next, based on the occupancy and usage patterns, the HVAC was redesigned assuming more area under the secondary HVAC unit. The trained algorithm was then used to make energy usage predictions for the revised primary HVAC area, with the assumption that the secondary HVAC unit was turned off. The results were compared with existing energy usage data. It was determined that there were significant energy savings in the second scenario. It is expected that this study and its findings will help future research projects explore more ideas as alternatives to central HVAC, in improving the economic viability of existing options, and in developing a savings calculation tool that will help consumers make informed decisions on their best alternatives to central HVAC.

• The Journal of Economics, Marketing and Management
• /
• v.11 no.6
• /
• pp.35-41
• /
• 2023

Purpose: This study aims to determine the marketability of the heritage sites in Region III, Philippines. More specifically, it will obtain information on the: (a) profile of the heritage sites in Central Luzon; (b) dimensional issues of their marketability along social, environmental, and economic lines; (c) quality of services in terms of tangibility, responsiveness, empathy, assurance, and reliability; and (d) its business model canvas. Research design, data, and methodology: This will utilize a descriptive survey of the heritage sites in Central Luzon, namely: Aurora, Nueva Ecija, Bulacan, Pampanga, Tarlac, Zambales, and Bataan. There will be 60 respondents, including 5 facilitators, 24 residents, and 31 tourists. The results will be statistically measured through the measures of central tendencies, dispersion, and the test of significance. Result and conclusion: This study will comprehensively examine the local tourism sector, benefiting various stakeholders. It serves as a valuable resource for tourists by providing insights into destination marketing strategies and enhancing heritage tourism experiences. Administrators benefit from coping strategy evaluations, aiding in the formulation of effective strategies aligned with industry goals. Tourism businesses align with industry objectives and the study streamlines ordinances for site protection for local government units. Additionally, the community gains empowerment through insights into employable activities and potential businesses, influencing assessments of the justification for local preservation ordinances.