• Journal of the Korean Association of Geographic Information Studies
• /
• v.22 no.1
• /
• pp.39-50
• /
• 2019

Since the "Special Law on Cadastral Resurvey" was enforced in 2012, the Cadastral Resurvey Project in South Korea has been promoted in earnest. However, it has been difficult to obtain the following items: a budget for the project, the establishment of land boundaries by increasing/decreasing the area of the parcels of land in the downtown area, the calculation of the adjustment fee, and the analysis of the relationship between the business owner and the landowner in regards to conflicts of opinion. The analysis of Japan's private-public boundary system, which is promoting the Cadastral Resurvey ahead of South Korea, should not attempt to determine complex interests, especially when they are pursuing consensus of the boundary setting portion of the Cadastral Resurvey Project. Therefore, this study shows that there is a need to reduce the number of stakeholders and promote them by using a step-by-step process. The introduction of cost-saving measures for the Cadastral Resurvey through a private-public boundary preliminary investigation is needed. This study suggested the following: link the precision road map construction business using MMS, introduce the preliminary research projects for the Cadastral Resurvey, and gather the important land survey information for the private-public boundary basic survey. In order to establish the utilization base, the researcher proposed linking the downtown area regeneration with the downtown area planning business.

• The Korean Journal of Archival Studies
• /
• no.40
• /
• pp.29-60
• /
• 2014

The purpose of this study is to trace the formation process of "parallel provenance" concept in the context of Australia's aboriginal community archives development and draw its implications for contemporary rebuilding of domestic "past affairs-related committee archives". Focused on historical development of aboriginal community archives in Australia, this writing divides its development into three periods: colonial archives, post-colonial archives, and contemporary archives and investigates each period's distinct features in managing and building of aboriginal community archives. First of all, for colonial archives, it pays attention to Australia's archival tradition, which focused on current record-keeping and then development of multiple provenance resulted from this tradition. Second, for post-colonial archives, it examines the appearance of aboriginal people as the subject of documentation category and name indexing on them. Finally, for contemporary archives, it analyzes current activities of Australia's academic world of archival science for overcoming "the otherness" of aboriginal people through conceptualization of "parallel provenance". Conclusively, through current meaning of parallel provenance, this study draws implications for democratic contemporary rebuilding of domestic past affairs-related committee archives, in which historical victims become the subject of archives.

• Journal of Internet Computing and Services
• /
• v.22 no.4
• /
• pp.123-134
• /
• 2021

This paper suggests that the Internet is not free through analysis of U.S. Internet history and lawsuits related to the Charter merger in 2016. Generally speaking, the players in internet connectivity market agree to Non-Disclosure Agreement, when connecting their facilities and networks each other. So, I adopted the case study & analysis as research methodologies due to limitation of collecting the transaction data between them. The former finds that Internet access has never been free in U.S Internet history. As we know, some including Content Providers(CPs) argue that the Internet is a free network and there are many cases to use the internet for free, so they came to conclusion that ISPs have no right to charge the users like CPs. This study refutes these arguments in two ways. One is that using the internet has never been free. From ARPANET, known as the beginning of the U.S. Internet, to the commercialization of backbone, no Internet has been considered or implemented for free since the early Internet network was devised. Also, the U.S government was paying subsidies or institutions were paying fees to secure network operations for the NSFNET backbone. the other is that "free peering" refers to barter transactions between ISPs, not to free access to counterpart internet networks. Second, this study analyze the FCC' executive order of conditioned merger approval and the court's related ruling and verify that using the internet is not free. According to the analysis, this study finds that it's real situation to make paid settlements between ISP-CPs (including OTTs) in the US Internet market at the moment. This study concludes that the Internet has never been free in terms of its technical characteristics, network structure, network operation, and system. Also it proposes how to improve the domestic settlement system between ISPs-CPs in terms of policy and regulation.

• Journal of Family Resource Management and Policy Review
• /
• v.26 no.3
• /
• pp.35-48
• /
• 2022

This study aims to investigate prejudiced descriptions of adoption and adoptive families in the major textbooks in the field of child and family welfare studies. To this end, we analyzed the compositions and contents of eleven different textbooks and found four necessary changes to recommend: first, we found it essential for authors to have a comprehensive understanding of the characteristics of the open adoption culture and adoptive families. Second, we observed the need for the revision of prejudiced terminology found in textbooks' descriptions of adoptive families - about adopters, adoptees, and adoption institutions. Third, we advise an enhancement in the understanding of adoptive families reflecting both qualitative and quantitative understandings of the open adoption culture and perspective about social prejudice against adoptive families. Finally, we advocate for the inclusion adoptive families as one of the diverse forms a family can take, not only in the curriculum of child (children's rights) studies but also in the curricula of other family-related disciplines such as family welfare and healthy family theory. Based on these four changes, we propose a new approach to authoring including a multifaceted review of the subject composition and the content of the major textbooks and revision of the overall contents of the textbooks.

• Korean Association of Arts Management
• /
• no.51
• /
• pp.191-219
• /
• 2019

Adoption of applicable law for the international trade of artworks is closely related to the results of lawsuits. Recently, starting with New York, the hub of the international artworks market, a modern, mixed-law is gradually being adopted more. It is difficult to designate an applicable law of an international trade of artworks through private laws regulations of relevant countries, and the public laws regulations must also be considered in relation to individual benefits and the public benefits to the relevant countries. With regards to the foreign relations issues, Korea's private international law embraces a so-called public order theory, and according to the Section 7 of the Act on the Private International Law and its enactment history, the compulsory provision, which seems appropriate for application to the corresponding matter, applies without regards to the selection of the applicable law. The Civil Act of Korea acknowledges bona fide acquisition of a cultural asset, in principle, if the Cultural Heritage Protection Act is not applicable. Moreover, a lost artwork is also a subject of bona fide acquisition; however, if the relevant artwork is either stolen or lost, the original owner has the right to demand the return of that artwork within 2 years of being stolen or lost according to the Section 250 of the Civil Act. Also, if the buyer purchased from a distributor specializing in the artworks, such as auction, open market or gallery, the buyer could request a compensation of the purchase price from the original owner, and if the buyer purchased through a private transaction, the buyer cannot demand a compensation of the purchase price and must return the artwork.

• Journal of the Korean association of regional geographers
• /
• v.23 no.3
• /
• pp.459-469
• /
• 2017

Recently, the third mission as the new role of the university is being emphasized as contributing to the local community through active participation in local and regional problems as well as an economic contribution as an entrepreneurial university. Thus, overseas universities started various university-industry collaboration activities targeting sustainable development based on local community and improve their roles for regional regeneration and innovation. Universities in Korea also tend to set up a cooperative governance with various agents in the local community via university financial support projects by the government and started to promote the university-industry collaboration project for solving the problem of the local community. Therefore, this research tries to find implications in order to expand the role and responsibility as local university and reinforce substantiality and enhancement of university-industry collaboration through a case analysis of university-industry collaboration to solve the problem in local communities in foreign countries. In order to solve the problem of local communities based on local agents-led small-sized projects, it is requested to improve the more active role of the university, local governments and university students.

• Korean Journal of Construction Engineering and Management
• /
• v.24 no.1
• /
• pp.12-20
• /
• 2023

To calculate the amount of owner-caused and contractor-caused delays based on a simplified delay analysis, which has been customarily used in Korea, has a limitation in reflecting the impact of the concurrent delay and the acceleration work. It also resulted in the apportionment of liquidated damages by applying the ratio of the number of delays between the owner and the contractor. This study analyzes that the conventional method does not meet the international standards. In order to improve the problem of construction delay analysis and the apportionment of liquidated damages based on it, owner delays, contractor delays, concurrent delays, and the impact of acceleration should be analyzed together. This study suggests that in the apportionment of liquidated damages, the extension of time should be extended by the sum of concurrent delays and the owner-caused delays, and liquidated damages should be imposed on delays incurred after the extension of time. It can be seen that it conforms to the international standards. The results of this study are expected to contribute to improving the problems of delay analysis and liquidated damages calculation, which have been conventionally accepted.

• 한국노년학
• /
• v.39 no.2
• /
• pp.305-323
• /
• 2019

In recognition of the increasing social attention paid to the notion of how to die well, this study explored what it is that middle-aged and older Koreans think of as "dying well." Specifically, it was aimed at classifying the perceptions people middle-aged and older have regarding dying well. To this end, we used data from the National Survey on Well-Dying, which was conducted in 2018 by the Korea Institute for Health and Social Affairs, and employed Latent Class Analysis. The demographic characteristics of each of the classified subgroups were identified through technical statistics. The types identified were multilayered depending on the imminence of death, perspectives of the last stages before dying, and the meaning of death in the context of social relationships. These types differed according to gender and subjective health conditions. Based on our findings in this study, we put forward policy suggestions about awareness improvement of personal and social levels, promoting on comprehensive death preparation, providing a system to reduce the cost of medical and nursing expense at the end of one's life, promoting of the right to self-determination regarding death, raising social attention to groups that are least prepared for dying well.

• 한국노년학
• /
• v.39 no.1
• /
• pp.1-20
• /
• 2019

Recently, the Ministry of Health and Welfare has emphasized the necessity to build community care, and the interest of health care- long-term care-social welfare system continues. In order to examine the future vision of long-term care for elderly people, which can be a core system in establishing community models for elderly people in the future, we will implement aging in place as a national policy project. It is meaningful to analyze in depth the case of Japan's policy implementation through the amendment process of long-term care insurance system. The purpose of this study is to examine the concept definition, operating system, and major promotion process of the Integrated Care System in Japan and to suggest policy implications for the future Korea long-term care insurance system. As a result of reviewing the operation status and revision process of the long-term care insurance system for establishing the Integrated care system in Japan, it is necessary to clarify the basic principles and construction of community care system, diversification of residence type and upgrading work, establishment of linkage network of health care-long term care-social welfare, expansion of support for family and self-mind.

• Journal of Korea Port Economic Association
• /
• v.39 no.3
• /
• pp.1-19
• /
• 2023

After being kept in bonded areas and bonded logistics warehouses, the level of information sharing and progress confirmation on the process until the cargo is released is insufficient, resulting in disputes and legal disputes related to unauthorized and illegal delivery of cargo. This study attempted to present the introduction of standard electronic documents as a way to solve problems such as delivery practices raised in the delivery of existing imported cargo and legal disputes related to unauthorized illegal delivery among import-related entities. The service provider who manages the bonded warehouse/logistics center in the hinterland of Busan New Port and the shipper service user who use the service were classified into two groups, and a survey was conducted to analyze the difference in perception between the two groups. As a result of the analysis, both groups judged that the introduction of standard electronic documents was necessary, and showed high expected effects in preventing and reducing erroneous shipments and preventing and improving unauthorized and illegal shipments. Discussions between related organizations, related parties, and subjects are needed first to introduce standard electronic documents of the entry and warehouse management system, and the actual participation of related entities such as service providers and service users will play a very important role in establishing the system.