Journal of Construction Engineering and Project Management
/
v.7
no.1
/
pp.13-25
/
2017
Construction projects have been observed to have problems of project delays and disruptions and the South African construction industry is not an exception. This research identified causes and effects of project delay and disruption through a desktop study. Subsequently, a questionnaire was designed and used to conduct a survey to obtain the views of the three main construction project participants - clients, consultants, and contractors. The questionnaire contains 48 causes and 13 effects of project delay and disruption identified from the desktop study. This research identified sixteen most important causes of project delay and disruption and five most important effects of delay and disruption. Sixteen most important causes were: (1) strikes, (2) rework due to errors during construction, (3) shortage of materials in market, (4) suspension of work by the client, (5) poor communication between the parties, (6) ineffective planning and scheduling of project, (7) delays in issuing working drawings, (8) mistakes and discrepancies in design documents, (9) shortage of labours and equipment, (10) delay in decision making process by the client, (11) unforeseen ground conditions, (12) unclear and inadequate details in drawing, (13) inadequate contractor's experience, (14) delay in approving changes in the scope of works, (15) delay in material delivery and (16) unacceptable quality of materials. The five major effects include: (1) create stress on contractors, (2) cost overrun, (3) time overrun, (4) poor quality of work due to rush, and (5) disputes. Furthermore, the result of this research was compared with the result of previous studies conducted in other regions of Africa in terms of causes and effects of project delay and disruption. The research concludes that numerous causes and effects of delay and disruption are limited to South African construction projects based on the comparison. The causes limited to South African construction projects include: (1) strikes, (2) suspension of work by the client (3) mistakes and discrepancies in design documents (4) delay in approving changes in the scope of works and (5) unacceptable quality of materials, while the two major effects limited to South African construction projects includes: (1) create stress on contractors and (2) poor quality of work. In conclusion, some recommendations were made in order to minimise the causes of delay and disruption identified.
The dynamic system approach in time series has been used in many real problems. Based on Taken's embedding theorem, we can build the predictive function where input is the time delay coordinates vector which consists of the lagged values of the observed series and output is the future values of the observed series. Although the time delay coordinates vector from multivariate time series brings more information than the one from univariate time series, it can exhibit statistical redundancy which disturbs the performance of the prediction function. We apply dimension reduction techniques to solve this problem and analyze the effect of this approach for prediction. Our experiment uses delayed Lorenz series; least squares support vector regression approximates the predictive function. The result shows that linearly preserving projection improves the prediction performance.
International Journal of Computer Science & Network Security
/
v.23
no.1
/
pp.153-163
/
2023
This study is situated in the context of intelligent transport systems, where in-vehicle devices assist drivers to avoid accidents and therefore improve road safety. The vehicles present in a given area form an ad' hoc network of vehicles called vehicular ad' hoc network. In this type of network, the nodes are mobile vehicles and the messages exchanged are messages to warn about obstacles that may hinder the correct driving. Node mobilities make it impossible for inter-node communication to be end-to-end. Recognizing this characteristic has led to delay-tolerant vehicular networks. Embedded devices have small buffers (memory) to hold messages that a node needs to transmit when no other node is within its visibility range for transmission. The performance of a vehicular delay-tolerant network is closely tied to the successful management of the nodes' transit buffer. In this paper, we propose a message transit buffer management model for nodes in vehicular delay tolerant networks. This model consists in setting up, on the one hand, a policy of dropping messages from the buffer when the buffer is full and must receive a new message. This drop policy is based on the concept of intermediate node to destination, queues and priority class of service. It is also based on the properties of the message (size, weight, number of hops, number of replications, remaining time-to-live, etc.). On the other hand, the model defines the policy for selecting the message to be transmitted. The proposed model was evaluated with the ONE opportunistic network simulator based on a 4000m x 4000m area of downtown Bouaké in Côte d'Ivoire. The map data were imported using the Open Street Map tool. The results obtained show that our model improves the delivery ratio of security alert messages, reduces their delivery delay and network overload compared to the existing model. This improvement in communication within a network of vehicles can contribute to the improvement of road safety.
Kim, Young-jae;Kim, Tae-kyoung;Jo, Duk-sang;Lee, Hwang-ku
Korean Journal of Construction Engineering and Management
/
v.16
no.3
/
pp.165-176
/
2015
Recently many Korean large-sized construction companies as well as specialty contractors have been expanding their business in the overseas market to mitigate impacts from long-term stagnation in the domestic market. Such as a result, it has been arisen as a major issue that contractors effectively manage the delays which have been commonly faced with in international mega-projects. Therefore it can be said that the ability of the delays management leads a success of project. This paper presents a review of literature for delay analysis methods such as time impact analysis(TIA) and raises practical problems to rationally substantiate the duration of extension of time(EoT) in international mega projects which have wide scope of works as well as complicated and detailed contract baseline programs by taking theoretical approaches. We suggest the two improvement concepts to substantiate the EoT claims which are effectively applicable to practical projects. The first is to sort out dominant delays among numerous delays in advance of applying a delay analysis. The second is to set up the delay sections with the advanced concept for analysing delays' effects by TIA. This study performed a case study on an actual international mega-project. to confirm the effectiveness of improvement concepts that this practical approach is applicable for the assessment of EoT. In conclusion, this paper supposes to provide practitioner in charge for an EoT claim with an advanced substantiation methodogy when they not only analyse the construction delays by using TIA, but also negotiate with stakeholders about with the assessment of EoT.
Jamal, Md Shah;Abdelaty, Ahmed;Shrestha, K. Joseph
International conference on construction engineering and project management
/
2022.06a
/
pp.616-623
/
2022
Some regions and states, such as Wyoming, have harsh weather conditions, forcing most transportation projects to be completed under tight schedules. However, construction projects are not only delayed by weather conditions, but also delayed by other factors such as contractor's competency, resource availability, coordination issues, and safety. Also, the construction method, geographical location of the projects, and inability to follow baseline schedules accurately due to the contractor's resource allocation are also reasons for the delay. This paper discusses the main reasons for the delay in the public transportation projects based on Daily Work Reports (DWRs) from five different transportation projects of the last three years in Wyoming. This paper focuses on the inconsistencies of the contractor's schedules to complete the project according to the baseline schedule. First, the authors collected DWRs and baseline schedules from the Wyoming Department of Transportation (WYDOT). Second, the DWR data are compared against the baseline schedules to determine the reasons for delaying their significance. Finally, the paper presents the recommendations to mitigate the effects of delays on public transportation projects as well as to improve the documentation process of DWR data.
KSII Transactions on Internet and Information Systems (TIIS)
/
v.10
no.8
/
pp.3551-3567
/
2016
The Low Earth Orbit satellite network has the unique characteristics of the non-uniform and time-variant traffic load distribution, which often causes severe link congestion and thus results in poor performance for delay-sensitive flows, especially when the network is heavily loaded. To solve this problem, a novel adaptive routing algorithm, referred to as the delay-oriented adaptive routing algorithm (DOAR), is proposed. Different from current reactive schemes, DOAR employs Destination-Sequenced Distance-Vector (DSDV) routing algorithm, which is a proactive scheme. DSDV is extended to a multipath QoS version to generate alternative routes in active with real-time delay metric, which leads to two significant advantages. First, the flows can be timely and accurately detected for route adjustment. Second, it enables fast, flexible, and optimized QoS matching between the alternative routes and adjustment requiring flows and meanwhile avoids delay growth caused by increased hop number and diffused congestion range. In addition, a retrospective route adjustment requesting scheme is designed in DOAR to enlarge the alternative routes set in the severe congestion state in a large area. Simulation result suggests that DOAR performs better than typical adaptive routing algorithms in terms of the throughput and the delay in a variety of traffic intensity.
This study has been performed to identify intelligent ability, reward choice in assumed situation of delay of gratification, and delay of gratification ability. The subjects for this study were 100 preschoolers between the ages of 4 and 5, their mothers, and 15 teachers of three day-care centers in Seoul. T-test, F-test, Correlation analysis and multiple regression analysis were used for data analysis. The main results of this study were as follows: First, preschoolers' delay of gratification ability by mothers' educational background was significant and delay of gratification ability by sex was significant. This means that mothers who had a higher educational background were positively related to preschoolers' delay of gratification ability. Second, in an assumed situation of delay of gratification, preschoolers' delay of gratification ability by reward choice was not significant. Third, delay of gratification by intelligent ability was significant. Fourth, the correlation among intelligent ability, reward choice in assumed situation of delay of gratification and delay of gratification ability were significant. Finally, preschoolers' delay of gratification ability was significantly influenced by two factors: reward choice in assumed situation of delay of gratification and preschoolers' intelligent ability.
Proceedings of the Korean Institute Of Construction Engineering and Management
/
autumn
/
pp.426-429
/
2003
In the construction process, there are many change orders differing to the initial contracts came from the social needs and environmental changes. Most of them will impact to the construction process so that its effects occur project delays. Time extension and liquidated damage in the construction process come from schedule delay whether it is excusable or not non-excusable by the owner. However, those become the delay claims if the owner and the contractor are not agreed on this situation. One of the most important thing on the delay claims is the calculation of delay. The purpose of this study is to present the method of the time delay calculation by comparison of As-Planned schedule, As-Built schedule including all delay and As-Built schedule absent owner delay.
The Journal of Korean Institute of Communications and Information Sciences
/
v.19
no.3
/
pp.434-441
/
1994
In this paper, performance of MAP management system traffic is analyzed, to realize the network management function in automated manufacturing network mini-MAP. The network management system, which controls and supervises the network resources in the communication network, is the function that is necessarily required in this network. Since the real time response must be required in the Mini-MAP network, the delay performance of the network needs to be analyzed. By means of both analytical method and simulation for cyclic queueing model, the delay time distributions due to the increasement of transmission data are obtained in the implemented management network where SLAM II package is used for simulation. In addition, the parameters of the management function affecting the transmission delay are considered so that these parameters can be used to implement network management system.
Journal of Korea Society of Digital Industry and Information Management
/
v.6
no.1
/
pp.83-90
/
2010
DTNs (Delay Tolerant Networks) refer to the networks that can support data transmission in the extreme networking situations such as continuous delay and no connectivity between ends. DTMNs (Delay Tolerant Networks) are a specific range of DTNs, and its chief considerations in the process of message delivery in the routing protocol are the transmission delay, improvement of reliability, and reduction of network loading. This article proposes a new LCN (Largest Common Neighbor) routing algorism to improve Spray and Wait routing protocol that prevents the generation of unnecessary packets in a network by letting mobile nodes limit the number of copies of their messages to all nodes to L. Since higher L is distributed to nodes with directivity to the destination node and the maximum number of common neighbor nodes among the mobile nodes based on the directivity information of each node and the maximum number of common neighbor nodes, more efficient node transmission can be realized. In order to verify this proposed algorism, DTN simulator was designed by using ONE simulator. According to the result of this simulation, the suggested algorism can reduce average delay and unnecessary message generation.
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.