건설시장의 개방과 함께 보다 다양화되고 국제화된 건설문화를 받아들이게 된 시점에서 우리나라 건설문화수준 및 정책은 아직 국제기준에 미치지 못하고 있는 실정이다. 그 예로 시공자 귀책사유로 인한 공기지연시 위약금 성격의 지체상금 산정방법은 손해배상금 성격의 국제기준과 차이를 보여 추후 잠재적 클레임의 가능성을 지닌다. 이에 본 연구는 지체상금 산정방법을 국제기준 및 공기연장비용과의 비교 ${\cdot}$ 분석을 통해 실제 발생되는 항목을 선정하여 손해배상금 성격의 지체상금 산정방법 개선방안을 위한 기초연구를 진행하였다.
Journal of Construction Engineering and Project Management
/
제7권3호
/
pp.1-14
/
2017
Delay claim should actually be supported by a set of proper information so that the contractors could prove their validity. The so-called information should be able to clarify the relationship between delay events and how they impact on the whole project. Therefore, exploiting an integrated system by people who are involved in construction business would certainly prove helpful. In the present study, delay analysis methods have been investigated along with selecting a relatively comprehensive method which has been modified, and eventually, a novel model and its required modules have been proposed for evaluating delay claims. The suggested integrated model is formed to identify delayed events, to classify delays, to measure the impacts of delays on the project scheduling, and finally to estimate the damages which were caused by those so-called delays. A decision support system (DSS) model which is related to the integrated system is actually extracted from Iran's general contract conditions, that is, 4311 magazine (equivalent to red FIDIC book). It is then programmed and coded by C# program. This DSS model can be used as an input of Easy Plan program. In addition, at the end of this research, the coded DSS has been used along with the so-called program so that a modified and developed model could be generated.
2004년 5월에 폴란드와 다른 동유럽 국가들이 EU에 가입되었다. EU에 가입 후에 폴란드는 도로부분의 투자 현실화를 촉진할 수 있을 것이고, 2005년에 도로 네트워크 상태의 중요한 개선을 이룰 수 있을 것이다. 폴란드 정부는 고속도로의 건설에 요구되는 전체 투자를 하는 것이 불가능하므로, 공공$\cdot$민간 파트너쉽에 기반한 프로젝트 투자의 최신의 기법을 개발하기를 원한다. 높은 품질의 교통 네트워크 없이는 경제적인 경쟁을 할 수가 없다. 이것은 EU에서 유럽 교통 네트워크를 구축하려고 하는 이유 때문이다. 유럽 교통 네트워크는 서유럽의 15개국과 폴란드와 같이 새로 가입된 회원국들 사이에 연결 고리를 제공해 줄 것이다. 그 결과로서, 폴란드는 향상된 교통 기반시설 네트워크를 확립할 것이다.
Since the 1970s, international construction employers have commonly requested first demand guarantees upon their contractors as a form of security for due performance of their works. Contractors prefer the greater protection offered by more traditional forms of security requiring presentation of an arbitral award or other evidence of the caller's entitlement to compensation. Many contractors nonetheless feel that they have no alternative but to provide these unconditional guarantees in order to compete. However, these unconditional first demand guarantees are controversial and have given rise to numerous disputes both in arbitration and litigation. Disputes arising from first demand guarantees can be broken down into a) applications to prevent a perceived fraudulent or otherwise unfair or improper calling of a guarantee, b) claims arising from such abusive calls and c) claims relating to the consequences of such calls even if the call itself may not be abusive as such. The contractors should carefully assess the risk of an abusive call being made bearing in mind the difficulties he may face in seeking to prevent such a call. He should also bear in mind the difficulties, delays and cost he is likely to encounter in seeking to recover any monies wrongfully called. One option would be to provide that the call can only be made once and to the extent that the employer's damages have been assessed or even incurred or even for the default to have been established by an arbitral tribunal or court. Another option would be to provide that any call be accompanied by a decision of a competent and impartial third party stating that the contractor is in breach. For example, such a requirement could be incorporated into a construction contract based on the FIDIC Conditions by submitting this decision to a Dispute Adjudication Board. Another option would be to provide for the "ICC Counter-Guarantee Scheme". In sum, there would appear to be room for compromise between the employer and the contractor in respect of first demand guarantees by conditioning the entitlement to call such guarantees to the determination of a competent and impartial third party.
최근 대형 건설회사의 해외시장 비중 확대와 함께 해외 프로젝트에서의 공기지연에 따른 경영 손실에 대한 이슈가 지속적으로 제기되고 있다. 일반적으로 대형 프로젝트의 수행 과정에서 변경은 필연적으로 발생한다. 대부분의 변경은 공기지연과 연결되기 때문에 변경으로 인하여 공기연장이 필요한 경우 건설사는 계약에서 정한 기준에 따라 공기지연을 관리해야 공기지연에 따른 리스크에 효과적으로 대응할 수 있다. 공기지연을 유발하는 변경에 대한 계약적 대응이 부족할 경우 클레임이 해결되지 않고 분쟁으로 확대되는 경우가 많다. 프로젝트 초기 단계에 계약에서 요구하는 공기지연 관리 절차와 방법을 분석하는 것이 중요하나 이에 대한 방법 및 도구를 제시하지 못하고 있었다. 본 논문에서는 국내 주요 건설사들의 공정관리 실무 및 해외 공사에서의 클레임 및 분쟁사례에 대한 고찰을 통해 문제를 제시하고 해외 건설 계약조건상에 포함된 공기지연 관리 리스크를 평가할 수 있는 방법을 제시하였다. 공기지연의 합리적 대응과 관련된 계약조건상의 리스크 평가 틀을 제시하기 위하여 FIDIC Red Book(1999), PSSCOC(2014) 및 SIA 9th Edition(2010) 등 국제 표준 계약조건 뿐만 아니라 ARAMCO 및 QP를 포함한 해외 대형 발주자의 표준계약조건에 나타나 있는 공기지연 관리 요건 및 수준을 검토하여 전체 7개 영역, 62개 항목으로 구성된 계약조건 리스크 평가모델을 제안하였다. 계약조건 리스크 평가 모델은 계약조건상의 공기지연리스크 확인을 위한 구조적 틀을 제공하며 개별 리스크 항목별 표준적인 수준을 제시함으로써 해당 프로젝트의 리스크 수준을 확인하고 이에 효과적으로 대응할 수 있는 단초를 제공한다. 제안된 모델의 유효성 검증을 위하여 실제 제안한 모델을 실제 프로젝트에 적용하여 그 효과를 입증하였다.
국내 건설수주 규모는 2013년 91.3조원에서 2021년 총 212조원으로 특히 민간부문에서 크게 성장하였다. 국내외 시장 규모가 성장하면서, EPC(Engineering, Procurement, Construction) 프로젝트의 규모와 복잡성이 더욱 증가되고, 이에 프로젝트 관리 및 ITB(Invitation to Bid) 문서의 위험 관리가 중요한 이슈가 되고 있다. EPC 프로젝트 발주 이후 입찰 절차에서 실제 건설 회사에게 부여되는 대응 시간은 한정적일 뿐만 아니라, 인력 및 비용의 문제로 ITB 문서 계약 조항의 모든 리스크를 검토하는데 매우 어려움이 있다. 기존 연구에서는 이와 같은 문제를 해결하고자 EPC 계약 문서의 위험 조항을 범주화하고, 이를 AI 기반으로 탐지하려는 시도가 있었으나, 이는 레이블링 데이터 활용의 한계와 클래스 불균형과 같은 데이터 측면의 문제로 실무에서 활용할 수 있는 수준의 지원 시스템으로 활용하기 어려운 상황이다. 따라서 본 연구는 기존 연구와 같이 위험 조항 자체를 정의하고 분류하는 것이 아니라, FIDIC Yellow 2017(국제 컨설팅엔지니어링 연맹 표준 계약 조건) 기준 계약 조항을 세부적으로 분류할 수 있는 AI 모델을 개발하고자 한다. 프로젝트의 규모, 유형에 따라서 세부적으로 검토해야 하는 계약 조항이 다를 수 있기 때문에 이와 같은 다중 텍스트 분류 기능이 필요하다. 본 연구는 다중 텍스트 분류 모델의 성능 고도화를 위해서 최근 텍스트 데이터의 컨텍스트를 효율적으로 학습할 수 있는 ELECTRA PLM(Pre-trained Language Model)을 사전학습 단계부터 개발하고, 해당 모델의 성능을 검증하기 위해서 총 4단계 실험을 진행했다. 실험 결과, 자체 개발한 ITB-ELECTRA 모델 및 Legal-BERT의 앙상블 버전이 57개 계약 조항 분류에서 가중 평균 F1-Score 기준 76%로 가장 우수한 성능을 달성했다.
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.