The purpose of this study is to determine the indicators and the criteria to classify types of train delays of high-speed rail in South Korea. Types of train delays have divided into the chronic delays and the knock-on delays. The Indicators based on relevance, reliability, and comparability were selected with arrival delay rate of over five minutes, median of arrival delays of preceding train and following train, knock-on delay rate of over five minutes, correlation of delay between preceding train and following train on intermediate and last stations, average train headway, average number of passengers per train, and average seat usages. Types of train delays were separated using the Ward's hierarchical cluster analysis. The criteria for classification of train delay were presented by the Fisher's linear discriminant. The analysis on the situational characteristics of train delays is as follows. If the train headway in last station is short, the probability of chronic delay is high. If the planned running times of train is short, the seriousness of chronic delay is high. The important causes of train delays are short headway of train, shortly planned running times, delays of preceding train, and the excessive number of passengers per train.
Delay is one of the most critical issues for construction projects and leads to huge losses in both developing and industrialized countries. The construction sector in Rwanda, a rapidly-developing nation, is no exception. Delays can be mitigated only once we have identify their primary causes, and these may not be the same in each region. This study aims to ascertain the main critical factors responsible for delays in building construction in Rwanda through an intensive literature review and questionnaire survey. A total of 40 delay causative factors were obtained from a literature review and were further classified into nine major categories. The questionnaire survey was distributed to about 80 respondents from clients, contractors, and consultants. From the list of 40 different factors, the top twelve most critical causes were identified as stoppage of work due to cash flow constraints, delay in approving design documents, confidentiality of physical plan, price fluctuations and delay in approving significant change, change orders, delay in performing inspections, Ineffective project planning, inadequate drawing details, unqualified labor, lack of materials on the market and dishonesty.
The 4th International Conference on Construction Engineering and Project Management Organized by the University of New South Wales
/
pp.614-620
/
2011
Delays in completing construction projects have significant financial and social impact to all parties involved in the construction process and in particular in developing countries. This is very evident in most construction projects in Libya and in both public and private sectors. The research study was initiated by Libyan Government and the main aim of the project is to develop a new strategy in reducing the impact of delay factors. In order to achieve this, a number of objectives have been set-to conduct a comprehensive literature survey, to conduct a comparative study of the delay factors in project completion in both Libya and UK using semi structured questionnaire and finally, to identify and analyse the causes of delay and ranked them using frequency of occurrence and severity. The critical causes of delay for construction projects were quite different between Libya and UK. For the former, the most critical causes of delay in Libyan construction industry were low skills of manpower, changes in the scope of the project, slowness in giving instruction and poor qualification of consultant, while for the latter they were financial problems, bad weather conditions on the job site and change in the scope of project. Statistical experiments including Paired Samples T-Test, was run to test the significance of the survey data in both countries Libya and UK. The statistical results confirmed the collected data from the survey were significant.
Purpose: Stroke is a time-sensitive disease that could have reduced complications and mortality with timely diagnosis and treatment. This study aimed to analyze the causes of delay in detecting the clinical signs and symptoms of stroke. Methods: This retrospective observational study analyzed the emergency medical services reports of suspected stroke patients with positive predictive values on the Cincinnati Prehospital Stroke Scale. The study was conducted in Daejeon, Republic of Korea from January 1, 2016 through December 31, 2017. Results: Prolonged prehospital time was associated with high blood pressure, history of cerebrovascular disease, and incidences during daily activities, and sleep. High blood pressure and complications from a previous stroke strongly associated with the prolonged stroke-detection phase (p<.05). Total prehospital time was shortened when patients had evident stroke symptoms, such as decreased level of consciousness, dysarthria, and hemiplegia (p<.05). There was no significant difference in gender or age as a factor that delayed the total prehospital time of the suspected stroke patients. Conclusion: Many patients did not recognize the early clinical symptoms and signs of a stroke. Furthermore, risk factors, such as high blood pressure and history of stroke, prolonged the total prehospital time. Therefore, we need targeted interventions that educate about warning symptoms of stroke, along with emphasis on the importance of emergency calls to substantially reduce the prehospital delays.
공기지연이 발생하게 되면 그에 대한 추가적인 비용이 발생하게 되어 사업비의 증가를 초래하기 때문에 발주자와 시공자의 분쟁을 유발하는 중요한 원인이 된다. 공기지연으로 인해 발생한 분쟁의 원활한 해결을 위하여 공기지연분석에 대한 다양한 연구들이 수행되어져 왔으나, 기존의 공기지연 분석방법들은 주로 소규모 건축공사와 같은 단순하고 반복적인 공정들에 적용되는 연구들이 대부분이어서 경부고속철도와 같은 대규모의 선형적인 복합 건설공사에 적용하기에는 한계가 있었다. 본 연구에서는 이러한 전통적인 공기지연분석방법을 대규모 토목공사에 적용할 수 있도록 보완하여 대형 건설공사의 공기지연을 전체 프로젝트 관점에서 입체적으로 분석하였다. 먼저, 거시적 차원에서 공정진척도(S-curve)의 비교분석 등을 통해 공기 지연이 가장 많이 발생한 공구(공사구간)를 찾는 분석을 실시하였다. 이어서 거시적 분석으로 도출된 지연공구의 일정공정표를 분석하여 지연원인과 그에 따른 영향분석을 실시하였고, 지연원인의 책임소재에 따른 분석과 구조물 특성에 따른 분석도 병행하여 공기지연의 특징을 입체적으로 분석하였다. 이러한 다면적인(multilateral) 공기지연분석을 통해 경부고속철도의 개통일정을 지연시킨 가장 주된 구간은 서울~천안의 "2-1공구"인 것으로 나타났으며, 전체 약 5년의 공기지연 중 4년여의 공기지연이 이 공구에서 발생한 것으로 분석되었다. 주요 공기지연 원인으로는 최초 설계시 고속철도 교량의 동적거동을 고려를 하지 못해 재설계와 재시공으로 공기가 지연되었으며 또한 불충분한 지질조사로 시공 중에 폐광이 발견되어 노선변경을 했던 것에 크게 기인하는 것으로 나타났다. 마지막으로 경부고속철도에 대한 공기지연분석을 통하여 이와 유사한 대형 국책 사업의 계획에 있어서 고려해야할 사항을 제안하였다.
Construction projects are facing delay problems. Delays in construction have been immense effect on performance or satisfactory delivery of the project. Delays have been causing project cost overrun as well as it is a source of dispute hence damaging the relationship between the project participants. The purpose of this study was to explore the causes of delay risk through a field survey study. Data were collected from construction professionals working in owner, consultant and contractor organizations. All together 208 questionnaire instruments were used and analyzed by employing statistical tools (SPSS computer program). 19 delay factors were identified by this study, out of which following factors were critical: Frequent interruptions from public (local people, pressure group etc.), changed site condition, failure to provide required construction site, unrealistic project time estimation and design errors.
The purpose of this paper was to explore delay avoiding measures and strategies. The paper was based on previous work of authors on finding delay causes. Firstly, the paper has discussed about delay avoidance measures prescribed by the previous work. As the previous study identified five main causes of construction delays, various measures and strategies to overcome those delay problems have been discussed in sequence in the last sections. Major delay prevention strategies are: involving stakeholders in the project decisions, outreach program, realistic time and resource estimation, try to adjust the triple constraints of time, cost and scope, ensure fair and complete disclosure of information at an early stage of the construction project, contractor, itself should inquire about patent design errors prior to submitting its bid, owner should include in its contract with the consultant an indemnity (protection) clause etc.
본 논문은 BIM 기반 설계 검토를 통하여 사전에 방지된 설계 오류와 그 영향도를 통계적으로 분석한다. 이를 위하여 한국에서 수행되었던 2개 BIM 프로젝트에서 BIM 기반 설계 검토를 도입함으로써 발견되었던 약 800여건 이상의 설계오류를 설계 오류 발생 원인별(비논리적 오류, 도면 상이, 누락), 발생 공종별(구조, 건축, 설비)로 분류한다. 시공 이전에 발견된 설계 오류로 인하여 발생할 수 있는 재작업과 공사비, 공사기간, 품질에의 영향 여부를 해당 현장의 실무자와의 인터뷰를 통해서 분류하고, 설계 오류와의 확률적 관계를 로지스틱 회귀분석을 이용하여 분석한다. 분석결과, 설계 오류 발생원인이 공사비 증가, 공기 지연, 품질 저하, 재작업을 유발 확률 예측에 통계적으로 가장 유의미한 관계가 있었다. 두 개의 프로젝트에서 수집된 자료만을 활용하여 설계 오류 간의 관계를 분석하였지만 설계 오류의 특성의 관계가 유사하다는 점에서 의미가 있다고 할 수 있다. 향후에는 다수의 프로젝트에서 수집된 자료를 분석하여 이를 검증하고자 한다.
If the construction delays are occurred during the project execution, the contractual parties should inquire the delay causes and the contractual obligation. Due to the compensation of damages, the interested parties and the contractual parties are placed on the adverse situation. For reasonable of the claim and dispute, the contractual parties are needed the objective and systematic procedure method to analyze the delay. The purpose of this study is to propose a formal process model considering the case of construction delay-claims.
It is known that existence of irregular transmission time delay is a major bottleneck for application of advanced robot control schemes to internet telerobotic systems. In the internet teleoperation system, the irregular transmission time delay causes a critical problem, which is unstable and inaccurate. This paper suggests a practical internet teleoperation system with streaming buffer system, which consists of a buffer, a buffer manager, and a control timer. The proposed system converts the irregular transmission time delay to constant. So, the system effectively transmits the control input to a remote site to operate a robot stably and accurately. This feature enables short control input interval. That means the entire system has ...
본 웹사이트에 게시된 이메일 주소가 전자우편 수집 프로그램이나
그 밖의 기술적 장치를 이용하여 무단으로 수집되는 것을 거부하며,
이를 위반시 정보통신망법에 의해 형사 처벌됨을 유념하시기 바랍니다.
[게시일 2004년 10월 1일]
이용약관
제 1 장 총칙
제 1 조 (목적)
이 이용약관은 KoreaScience 홈페이지(이하 “당 사이트”)에서 제공하는 인터넷 서비스(이하 '서비스')의 가입조건 및 이용에 관한 제반 사항과 기타 필요한 사항을 구체적으로 규정함을 목적으로 합니다.
제 2 조 (용어의 정의)
① "이용자"라 함은 당 사이트에 접속하여 이 약관에 따라 당 사이트가 제공하는 서비스를 받는 회원 및 비회원을
말합니다.
② "회원"이라 함은 서비스를 이용하기 위하여 당 사이트에 개인정보를 제공하여 아이디(ID)와 비밀번호를 부여
받은 자를 말합니다.
③ "회원 아이디(ID)"라 함은 회원의 식별 및 서비스 이용을 위하여 자신이 선정한 문자 및 숫자의 조합을
말합니다.
④ "비밀번호(패스워드)"라 함은 회원이 자신의 비밀보호를 위하여 선정한 문자 및 숫자의 조합을 말합니다.
제 3 조 (이용약관의 효력 및 변경)
① 이 약관은 당 사이트에 게시하거나 기타의 방법으로 회원에게 공지함으로써 효력이 발생합니다.
② 당 사이트는 이 약관을 개정할 경우에 적용일자 및 개정사유를 명시하여 현행 약관과 함께 당 사이트의
초기화면에 그 적용일자 7일 이전부터 적용일자 전일까지 공지합니다. 다만, 회원에게 불리하게 약관내용을
변경하는 경우에는 최소한 30일 이상의 사전 유예기간을 두고 공지합니다. 이 경우 당 사이트는 개정 전
내용과 개정 후 내용을 명확하게 비교하여 이용자가 알기 쉽도록 표시합니다.
제 4 조(약관 외 준칙)
① 이 약관은 당 사이트가 제공하는 서비스에 관한 이용안내와 함께 적용됩니다.
② 이 약관에 명시되지 아니한 사항은 관계법령의 규정이 적용됩니다.
제 2 장 이용계약의 체결
제 5 조 (이용계약의 성립 등)
① 이용계약은 이용고객이 당 사이트가 정한 약관에 「동의합니다」를 선택하고, 당 사이트가 정한
온라인신청양식을 작성하여 서비스 이용을 신청한 후, 당 사이트가 이를 승낙함으로써 성립합니다.
② 제1항의 승낙은 당 사이트가 제공하는 과학기술정보검색, 맞춤정보, 서지정보 등 다른 서비스의 이용승낙을
포함합니다.
제 6 조 (회원가입)
서비스를 이용하고자 하는 고객은 당 사이트에서 정한 회원가입양식에 개인정보를 기재하여 가입을 하여야 합니다.
제 7 조 (개인정보의 보호 및 사용)
당 사이트는 관계법령이 정하는 바에 따라 회원 등록정보를 포함한 회원의 개인정보를 보호하기 위해 노력합니다. 회원 개인정보의 보호 및 사용에 대해서는 관련법령 및 당 사이트의 개인정보 보호정책이 적용됩니다.
제 8 조 (이용 신청의 승낙과 제한)
① 당 사이트는 제6조의 규정에 의한 이용신청고객에 대하여 서비스 이용을 승낙합니다.
② 당 사이트는 아래사항에 해당하는 경우에 대해서 승낙하지 아니 합니다.
- 이용계약 신청서의 내용을 허위로 기재한 경우
- 기타 규정한 제반사항을 위반하며 신청하는 경우
제 9 조 (회원 ID 부여 및 변경 등)
① 당 사이트는 이용고객에 대하여 약관에 정하는 바에 따라 자신이 선정한 회원 ID를 부여합니다.
② 회원 ID는 원칙적으로 변경이 불가하며 부득이한 사유로 인하여 변경 하고자 하는 경우에는 해당 ID를
해지하고 재가입해야 합니다.
③ 기타 회원 개인정보 관리 및 변경 등에 관한 사항은 서비스별 안내에 정하는 바에 의합니다.
제 3 장 계약 당사자의 의무
제 10 조 (KISTI의 의무)
① 당 사이트는 이용고객이 희망한 서비스 제공 개시일에 특별한 사정이 없는 한 서비스를 이용할 수 있도록
하여야 합니다.
② 당 사이트는 개인정보 보호를 위해 보안시스템을 구축하며 개인정보 보호정책을 공시하고 준수합니다.
③ 당 사이트는 회원으로부터 제기되는 의견이나 불만이 정당하다고 객관적으로 인정될 경우에는 적절한 절차를
거쳐 즉시 처리하여야 합니다. 다만, 즉시 처리가 곤란한 경우는 회원에게 그 사유와 처리일정을 통보하여야
합니다.
제 11 조 (회원의 의무)
① 이용자는 회원가입 신청 또는 회원정보 변경 시 실명으로 모든 사항을 사실에 근거하여 작성하여야 하며,
허위 또는 타인의 정보를 등록할 경우 일체의 권리를 주장할 수 없습니다.
② 당 사이트가 관계법령 및 개인정보 보호정책에 의거하여 그 책임을 지는 경우를 제외하고 회원에게 부여된
ID의 비밀번호 관리소홀, 부정사용에 의하여 발생하는 모든 결과에 대한 책임은 회원에게 있습니다.
③ 회원은 당 사이트 및 제 3자의 지적 재산권을 침해해서는 안 됩니다.
제 4 장 서비스의 이용
제 12 조 (서비스 이용 시간)
① 서비스 이용은 당 사이트의 업무상 또는 기술상 특별한 지장이 없는 한 연중무휴, 1일 24시간 운영을
원칙으로 합니다. 단, 당 사이트는 시스템 정기점검, 증설 및 교체를 위해 당 사이트가 정한 날이나 시간에
서비스를 일시 중단할 수 있으며, 예정되어 있는 작업으로 인한 서비스 일시중단은 당 사이트 홈페이지를
통해 사전에 공지합니다.
② 당 사이트는 서비스를 특정범위로 분할하여 각 범위별로 이용가능시간을 별도로 지정할 수 있습니다. 다만
이 경우 그 내용을 공지합니다.
제 13 조 (홈페이지 저작권)
① NDSL에서 제공하는 모든 저작물의 저작권은 원저작자에게 있으며, KISTI는 복제/배포/전송권을 확보하고
있습니다.
② NDSL에서 제공하는 콘텐츠를 상업적 및 기타 영리목적으로 복제/배포/전송할 경우 사전에 KISTI의 허락을
받아야 합니다.
③ NDSL에서 제공하는 콘텐츠를 보도, 비평, 교육, 연구 등을 위하여 정당한 범위 안에서 공정한 관행에
합치되게 인용할 수 있습니다.
④ NDSL에서 제공하는 콘텐츠를 무단 복제, 전송, 배포 기타 저작권법에 위반되는 방법으로 이용할 경우
저작권법 제136조에 따라 5년 이하의 징역 또는 5천만 원 이하의 벌금에 처해질 수 있습니다.
제 14 조 (유료서비스)
① 당 사이트 및 협력기관이 정한 유료서비스(원문복사 등)는 별도로 정해진 바에 따르며, 변경사항은 시행 전에
당 사이트 홈페이지를 통하여 회원에게 공지합니다.
② 유료서비스를 이용하려는 회원은 정해진 요금체계에 따라 요금을 납부해야 합니다.
제 5 장 계약 해지 및 이용 제한
제 15 조 (계약 해지)
회원이 이용계약을 해지하고자 하는 때에는 [가입해지] 메뉴를 이용해 직접 해지해야 합니다.
제 16 조 (서비스 이용제한)
① 당 사이트는 회원이 서비스 이용내용에 있어서 본 약관 제 11조 내용을 위반하거나, 다음 각 호에 해당하는
경우 서비스 이용을 제한할 수 있습니다.
- 2년 이상 서비스를 이용한 적이 없는 경우
- 기타 정상적인 서비스 운영에 방해가 될 경우
② 상기 이용제한 규정에 따라 서비스를 이용하는 회원에게 서비스 이용에 대하여 별도 공지 없이 서비스 이용의
일시정지, 이용계약 해지 할 수 있습니다.
제 17 조 (전자우편주소 수집 금지)
회원은 전자우편주소 추출기 등을 이용하여 전자우편주소를 수집 또는 제3자에게 제공할 수 없습니다.
제 6 장 손해배상 및 기타사항
제 18 조 (손해배상)
당 사이트는 무료로 제공되는 서비스와 관련하여 회원에게 어떠한 손해가 발생하더라도 당 사이트가 고의 또는 과실로 인한 손해발생을 제외하고는 이에 대하여 책임을 부담하지 아니합니다.
제 19 조 (관할 법원)
서비스 이용으로 발생한 분쟁에 대해 소송이 제기되는 경우 민사 소송법상의 관할 법원에 제기합니다.
[부 칙]
1. (시행일) 이 약관은 2016년 9월 5일부터 적용되며, 종전 약관은 본 약관으로 대체되며, 개정된 약관의 적용일 이전 가입자도 개정된 약관의 적용을 받습니다.